HomeMy WebLinkAbout4.02 DublinRch Tr7137&7138Bonds. Parkland dedication requirements have also been satisfied with payment of in lieu fees and credit
transfers.
In November 2002, Toll CA II, LP, signed the Tract Improvement Agreements, provided bonds, and
began constructing site improvements for Tracts 7137 and 7138. Most of the site improvements have
been completed. However, City Conditions of Approval and an Improvement Agreement with the Lin
Family did not permit the last Final Map in Area A to be approved until the Lin Family provided the City
with security for the construction of Fallon Road to the Lin's north property line. With the current
approval of the Amended Improvement Agreement for Fallon Road North with the Lins with bonds, Toll
CA II, LP, has now completed the purchase of the property and is proceeding with approvals of the Final
Maps.
A Tract Improvement Agreement, with Performance Bond, and Labor and Materials Bond, was preyiously
executed with Toll CA II, LP for landscaping improvements for the final four tracts in Area A (Tracts
7137, 7138, 7139 and 7140).
Staff recommends that the City Council adopt the resolutions approving the Final Tract Maps and Tract
Improvement Agreements for Tracts 7137 and 7138 and for the Acceptance of In Lieu Parkland
Dedication Fees and Credits.
Page2 rY~D~
RESOLUTION NO. - 04
A RESOLUTION OF THE CITY COUNCIL
OF THE CITY OF DUBLIN
APPROVING FINAL MAP FOR TRACT 7137
(DUBLIN RANCH AREA A-2, TOLL CA II, LP)
WHEREAS, the Final Map for Tract 7137, in the incorporated territory of the City of Dublin,
State of California, has been presented to this City Council for approval, all in accordance with provisions
of the Subdivision Map Act of the State of California and the City of Dublin Municipal Code; and
WHEREAS, the Developer, Toll CA II, LP, has executed and filed with the City of Dublin a
Tract Improvement Agreement to improve required subdivision improvements in accordance with the
Conditions of Approval for the Tentative Map, and the improvement plans attached thereto; and
WHEREAS, said Tract Improvement Agreement is secured by a bond furnished by the
Travelers Casualty and Surety Company in the amount of $354,255.00 for the tract drainage and street
improvements (Bond No. 103938729), conditioned upon faithful performance of said Agreement; and
WHEREAS, said Tract Improvement Agreement is secured by a bond furnished by the
Travelers Casualty and Surety Company in the amounts of $354,255.00 for the tract drainage and street
improvements (Bond No. 103938729), conditioned upon payment for labor performed or material
furnished under the terms of said Agreement; '
NOW, THEREFORE, BE IT RESOLVED that said agreement and bonds are hereby approved.
BE IT FURTHER RESOLVED that the Final Map of Tract 7137 be and the same is hereby
approved, and that rights to the areas marked as West Cog Hill Terrace, West Castle Pines Terrace,
Glenn Abbey Place, Public Service Easement (P.S.E.), and Public Access Easement (P.A.E.), offered
for dedication to public use in conformity with the terms of dedication be, and they are hereby accepted,
subject to improvement, and that the Clerk of this City Council is hereby directed to transmit said Map to
the County Recorder for filing.
PASSED, APPROVED AND ADOPTED this 3rd day of February, 2004.
AYES:
NOES:
ABSENT:
ABSTAIN:
ATTEST: Mayor
City Clerk
g:\develop\dublin ranchkarea aka 2-5 tracts 7137-40h'eso fm tract 7137.doc
EXHIBIT "A" TO RESOLUTION 04
CITY OF DUBLIN
TRACT IMPROVEMENT AGREEMENT
This agreement is made and entered into this 3rd day of February, 2004, by and
between the CITY of Dublin, a municipal corporation, hereinafter referred to as "CITY", and
Toll Ca II, L.P., a California limited partnership, hereinafter referred to as "DEVELOPER".
RECITALS
WHEREAS, it has been determined by the CITY Council of the CITY of Dublin, State
of California, that the DEVELOPER of Tract 7137, desires to improve and dedicate those
public improvements (hereafter "The Improvements") required by City of Dublin Planning
Commission Resolution No. 02-10 adopted on February 26, 2002 in accordance with the
requirements and conditions set forth in said resolution, the requirements of the Subdivision
Map Act of the State of California, the Subdivision Ordinance of the CITY, and those certain
plans for said development entitled Plans for the Improvement of Dublin Ranch Area A2 -
Tract 7137, prepared by MacKay & Somps and signed by the CITY on July 11, 2003,
and now on file in the office of the City Engineer, which are hereby referred to for a more
definite and distinct description of the work to be performed under this Agreement as though
set forth at length herein; and
WHEREAS, DEVELOPER intends to satisfactorily complete The Improvements within
the time hereinafter specified, and CITY intends to accept DEVELOPER's offer(s) of
dediCation of The Improvements in consideration for DEVELOPER's satisfactory performance
of the terms and conditions of this Agreement:
NOW, THEREFORE, in consideration of the mutual promises, conditions and
covenants herein contained, the parties agree as follows:
1. Completion Time.
DEVELOPER will commence construction of The Improvements within thirty (30) days
following the date on which CITY executes this Agreement. DEVELOPER shall complete
said work not later than five hundred and fifty (550) days following said date of execution.
Time is of the essence in this Agreement. Upon completion, DEVELOPER shall furnish CITY
with a complete and reproducible set of final as-built plans of The Improvements, including
any authorized modifications.
2. Estimated Cost of Improvements.
The estimated cost of constructing The Improvements required by this agreement as
presented in the Bond Estimate for Tract 7137, dated March 27, 2003 prepared by
MacKay and Somps is agreed to be $354,255.00. Said amount includes costs and
reasonable expenses and fees which may be incurred in enforcing the obligation secured.
3. Bonds Furnished.
Concurrently with the execution of this Agreement, DEVELOPER shall furnish CITY
with the following security in a form satisfactory to the CITY Attorney:
A. Faithful Performance. Either a cash deposit, a corporate surety bond issued
by a company duly and legally licensed to conduct a general surety business in the State of
California, or an instrument of credit equivalent to one hundred per cent (100%) of the
estimate set forth in Paragraph 2 and sufficient to assure CITY that The Improvements will be
satisfactorily, completed.
B. Labor and Materials. Either a cash deposit, a corporate surety bond issued
by a company duly and legally licensed to conduct a general surety business in the State of
California, or an instrument of credit equivalent to one-hundred per cent (100%) of the
estimate set forth in Paragraph 2 and sufficient to assure CITY that DEVELOPER'S
contractors, subcontractors, and other persons furnishing labor, materials, or equipment
shall be paid therefor.
C. If required by CITY, a cash deposit, corporate surety bond, or instrument of
credit sufficient .to assure CITY that the surface water drainage of the subdivision shall not.
interfere with the use 'of neighboring property, including public streets and highways.
CITY shall be the sole indemnitee named on any instrument required by this
Agreement. Any instrument or deposit required herein shall conform with the provisions of
Chapter 5 of the Subdivision Map Act.
4. Insurance Required.
Concurrently with th-e execution hereof, DEVELOPER shall obtain or cause to be
obtained and filed with the CITY, all insurance required under this paragraph, and such
insurance shall have been approved by the Administrative Services Director of CITY, or his
designee, as to form, amount and carrier. Prior to the commencement of work under this
Agreement, DEVELOPER's general contractor shall obtain or cause to be obtained and filed
with the Administrative Services Director, all insurance required under this paragraph, and
such insurance shall have been approved by the Administrative Services Director of CITY, as
to form, amount and carrier. DEVELOPER shall not allow any contractor or subcontractor to
,~qulred for ~"'~"-~ ,'~D~-~
commence work on this contract or subcontract until all insurance .... ' ~,-v --,.,,-,,
and DEVELOPER's general contractor shall have been so obtained and approved. Said
insurance shall be maintained in full force and effect until the completion of work under this
Agreement and the final acceptance thereof by CITY. All requirements herein provided shall
appear either in the body of the insurance policies or as endorsements and shall specifically
bind the insurance carrier.
A. Minimum Scope of Insurance. Coverage shall be at least as broad as:
1 ) Insurance Services Office form number GL 0002 (Ed. 1/73) covering
comprehensive General Liability and Insurance Services Office form number
GL 0404 covering Broad Form Comprehensive General Liability; or Insurance
Services Office Commercial General Liability coverage ("occurrence" form
CG 0001 .)
2) Insurance Services Office form number CA 0001 (Ed. 1/78) covering
Automobile Liability, code 1 "any auto" and endorsement CA 0025.
3) Workers' Compensation insurance as required by the Labor Code of the
State of California and Employers Liability Insurance.
B. Minimum Limits of Insurance. DEVELOPER shall maintain limits no less
than:
1) General Liability: $1,000,000 combined single limit per occurrence for
bodily injury, personal injury and property damage. If commercial General
Liability Insurance or other form with a general aggregate limit is used, either
the general aggregate limit shall apply separately to this project/location or the
general aggregate limit shall be twice the required occurrence limit.
2) Automobile Liability: $1,000,000 combined single limit per accident for
bodily injury and property damage.
3) Workers' Compensation and Employers Liability: Workers'
compensation limits as required by the Labor Code of the State of California
and Employers Liability limits of $1,000,000 per accident.
C. Deductibles and Self-Insurance Retentions. Any deductibles or self-
insured retentions must be declared to and approved by the CITY..At the optiOn of the
CITY, either the insurer shall reduce or eliminate such deductibles or self-insured
retentions as respects the CITY, its officers, officials and employees; or the
DEVELOPER shall procure a bond guaranteeing payment of losses and related
investigations, claim administration and defense expenses.
D. Other insurance Provisions. The policies are to contain, or be endorsed to
contain, the following provisions:
I) General Liability and Automobile Liability Covera,qes.
a) The CITY, its officers, agents, officials, employees and volunteers
shall be named as additional insureds as respects: liability arising
out of activities performed by or on behalf of the DEVELOPER;
products and completed operations of the DEVELOPER;
premises owned, occupied or used by the DEVELOPER; or
automobiles owned, leased, hired or borrowed by the
DEVELOPER. The coverage shall contain no special limitations
on the scope of the protection afforded to the CITY, its officers,
officials, employees or volunteers.
b) The DEVELOPER's insurance coverage shall be primary
insurance as respects the CITY, its officers, officials, employees
and volunteers. Any insurance or self-insurance maintained by
the CITY, its officers, officials, employees or volunteers shall be
excess of the DEVELOPER's insurance and shall not contribute
with it.
c) Any failure to comply with reporting provisions of the policies shall
not affect coverage provided to the CITY, its officers, officials,
employees or volunteers.
d) The DEVELOPER's insurance shall .apPly separately to each
insured against whom claim is made or suit is brought, except with
respect to the limits of the insurer's liability.
2) Workers' Compensation and Employers Liability Coveraqe.
The insurer shall agree to waive all rights of subrogation against the
CITY, its officers, officials, employees and volunteers for losses arising from
work performed by the DEVELOPER forthe CITY.
3) All Coveraqes.
Each insurance policy required by this clause shall be endorsed to state
that coverage shall not be suspended, voided, cancelled by either party, reduced in
coverage or in limits except after thirty (30) days' prior written notice.by certified mail,
return receipt requested, has been given to the CITY.
a) Acceptability of Insurers. Insurance is to be placed with insurers
with a Bests' rating of no less than A:Vll.
b) Verification of Coveraqe. DEVELOPER shall furnish CITY with
certificates of insurance and with original endorsements effecting
coverage required by this clause. The certificates and
endorsements for each insurance policy are to be signed by a
person authorized by that insurer to bind coverage on its behalf.
The ce,~ificates and endorsements are to be received and
approved by the CITY before work commences. The CITY
reserves the right to require complete, certified copies of all
required insurance policies, at any time.
c) SubcontractOrs. DEVELOPER and/or DEVELOPER's general
contractor shall include all subcontractors as insureds under its
policies or shall obtain separate certificates and endorsements for
each subcontractor. All coverages for subcontractors shall be
subject to all of the requirements stated herein.
5. Work Performance and Guarantee.
Except as otherwise expressly provided in this Agreement, and excepting only items of
routine maintenance, ordinary wear and tear and unusual abuse or neglect, DEVELOPER
guarantees all work executed by DEVELOPER and/or DEVELOPER's agents, and all
supplies, materials and devices of whatsoever nature incorporated in, or attached to the
work, or otherwise delivered to CITY as a part of the work pursuant t° the Agreement, to be
free of ali defects of workmanship and materials for a period of one (1) year after initial
acceptance of the entire work by cITY. DEVELOPER shall repair or replace any or all such
work or material, .together with all or any other work or materials which may be displaced or
damaged in so doing, that may prove defective in workmanship or material within said one-
year guarantee period without expense or charge of any nature whatsoever to CITY.
DEVELOPER further covenants and agrees that when defects in design, workmanship and
materials actually appear during the one-year guarantee period, and have been corrected,
the guarantee period shall automatically be extended for an additional year to insure that
such defects have actually been corrected.
In.the event the DEVELOPER shall fail to comply with the conditions of the foregoing
guarantee within thirty (30) days time, after being notified of the defect in writing, CITY shall
have the right, but shall not be obligated, to repair or obtain the repair of the defect, and
DEVELOPER shall pay to CITY on demand all costs and expense of such repair.
Notwithstanding anything herein to the contrary, in the event that any defect in workmanship
or material covered by the foregoing guarantee results' in a .condition which constitutes an
immediate hazard to the public health, safety, or welfare, CITY shall have the right to
immediately repair, or cause to be repaired, such defect, and DEVELOPER shall pay to CITY
on demand all costs and expense of such repair. The foregoing statement relating to
hazards to health and safety shall be deemed to include either temporary or permanent
repairs which may be required as determined in the sole discretion and judgment of CITY.
If CITY, at' its sole option, makes or causes to be made the necessary repairs or
replacements or performs the necessary work, DEVELOPER shall pay, in addition to actual
costs and expenses of such repair or work, fifty percent (50%) of such costs and expenses
for overhead and interest at the maximum rate of interest permitted by law accruing thirty (30)
days from the date of billing for such work or repairs.
6. Inspection of the Work.
D- ',/~LOP-R guarantee ~'^"
o.~,, ,,~ access to,.,,, , ,,,,,~uu- ,,o Public Works
Director/City Engineer and his designated representative for the safe an_d convenient
inspection of the work throughout its construction. Said CiTY representative shall have the
authority to reject all materials and workmanship which are not in accordance With the plans
and specifications, and all such materials and or work shale be removed promptly by
DEVELOPER and replaced to the satisfaction of CITY without any expense to CITY in strict
.accordance with the improvement plans and specifications.
7. Agreement Assiqnment.
This Agreement shall' not be assigned by DEVELOPER without the written consent of
CITY.
8. Abandonment of Work.
Neither DEVELOPER nor any of DEVELOPER's agents or contractors are or shall be
considered to be agents of CITY in connection with the performance of DEVELOPER's
obligations under this Agreement.
If DEVELOPER refuses or fails to obtain prosecution of the work, or any severable
part thereof, with such diligence as will insure its completion within thetime specified, or any
extension thereof, or fails to obtain completion of said work within such time, or if
DEVELOPER should be adjudged as bankrupt, or should make a general assignment for the
benefit of DEVELOPER's creditors, or if a receiver should be appointed, or if DEVELOPER,
or any of DEVELOPER's contractors, subcontractors, agents or employees should violate
any of the provisions of this Agreement, the CITY through its Public Works Director may
serve written notice on DEVELOPER and DEVELOPER's surety or holder of other security of
breach of this Agreement, or of any portion, thereof, and default of DEVELOPER.
In the event of any such notice of breach of this Agreement, DEVELOPER's surety
shall have the duty to take over and complete The Improvements herein specified; provided,
however, that if the surety, within thirty (30) days after the serving upon it of such notice of
breach, does not give CITY written notice of its intention to take over the performance of the
contract, and does not commence performance thereof within thirty (30) days after-notice: to
CITY of such election, CITY may take over the work and prosecute the same to completion,
by contract or by any other method CITY may deem advisable, for the account and at the
expense of DEVELOPER and DEVELOPER's surety shall be liable to CITY for any damages
and/or reasonable and documented excess costs occasioned by CITY thereby; and, in such
event, CITY, without liability for so doing, may take possession of, and utilize in completing
the work, such materials, appliances, plant and other property belonging to DEVELOPER as
may be on the site of the work and necessary therefor.
All notices herein required shall be in writing, and delivered in person or sent by
registered, mail, postage prepaid.
Notices required to be given to CiTY shall be addressed as follows:
City Manager
City of Dublin
100 Civic Plaza
Dublin, CA 94568
Notices required to be given to DEVELOPER shall be addressed as follows:
Toll Brothers, Inc.
100 Park Place, Suite 140
San Ramon, CA 94583
Notices required to be given surety of DEVELOPER shall be addressed as follows:
Toll Brothers, Inc
100 Park Place, Suite 140
San Ramon, CA 94583
Any party or the surety may change such address by notice in writing to the other party
and thereafter notices shall be addressed and transmitted to the new address.
Concurrently with the execution of this Agreement, DEVELOPER has executed and
has caused to be acknoWledged an abstract of this Agreement. DEVELOPER agrees CITY
may record said abstract in the Official Records of Alameda County.
9. Use of Streets or Improvements.
At all times prior to the final acceptance of the-work by CITY, the use of any or all
streets and improvements within the work to be performed under this Agreement shall be at
the sole and exclusive risk of DEVELOPER. The issuance of any building or occupancy
permit by CITY for dwellings located within the tract shall not be construed in any manner to
constitute a partial or final acceptance or approval of any or all such improvements by CITY.
DEVELOPER agrees that CITY's Building Official may withhold the issuance of building or
occupancy permits when the work or its progress may substantially and/or detrimentally
affect public health and safety.
10. Safety Devices.
DEVELOPER shall provide and maintain such guards, watchmen, fences, barriers,
regulatory signs, warning lights, and other safety devices adjacent to and on the tract site as
may be necessary to prevent accidents to the public and damage to the property.
DEVELOPER shall f. urnish, place, and maintain such lights as may be necessary for
illuminating the said fences, barriers, signs, and other safety devices. At the end of all work
to be performed under this Agreement, all fences, barriers, regulatory signs, warning lights,
and other safety devices (except such safety items as may be shown on the plans and
included in the items of work) shall be removed from site of the work by the DEVELOPER,
and the entire site left clean and orderly.
11. Acceptance of Work.
Upon notice of the completion of all tract work and the delivew of a set of final as-built
plans to CITY by DEVELOPER, CITY, through its City Engineer or his designated
representative, shall examine the tract work without delay, and, if found to be in accordance
with said plans and specifications and this Agreement, shall recommend acceptance of the
work to the City Council and, upon such acceptance, shall notify DEVELOPER or his
designated agents of such acceptance.
12. Patent and Copyright Costs.
In the event that said plans and specifications require the use of any material, process
or publication which is subject to a duly registered patent or copyright, DEVELOPER shall be
liable for, and shall indemnify CITY from any fees, costs or litigation expenses, including
attorneys' fees and court costs, which may result from the use of said patented or copyrighted
material, process or publication.
13. Alterations in Plans and Specifications.
Any alteration or alterations made in the plans and specifications which are a part of
this Agreement or any provision of this Agreement shall not operate to release any surety or
sureties from liability on. any bond or bonds attached hereto and made a part hereof, and
consent to make such alterations is hereby given, and the sureties to said bonds hereby
waive the provisions of Section 2819 of the Civil Code of the State of California.
14. Liability.
A. DEVELOPER Primarily Liable. DEVELOPER hereby warrants that the
design and construction of The Improvements will not adversely affect any portion of
adjacent propertiesand that all work will be performed in a proper manner.
DEVELOPER agrees to indemnify, defend, release, and save harmless CITY, and
each of its elective and appointive boards, commissions, officers agents and
employees, from and against any and all loss, claims, suits, liabilities, actions,
damages, or causes of action of every kind, nature and description, directly or
indirectly arising from an act or omission of DEVELOPER, its employees, agents, or
independent contractors in connection with DEVELOPER'S actions and obligations
hereunder; provided as follows:
1) That CITY does not, and shall not, waive any rights against
DEVELOPER which it may have by reason of the aforesaid hold harmless
agreement, because of the acceptance by CITY, or the deposit with CITY by
DEVELOPER, of any of the insurance policies described in Paragraph 4 hereof.
2) That the aforesaid hold harmless agreement by DEVELOPER shall
apply to all damages and claims .for damages of every kind suffered, or alleged
to have been suffered, by reason of any of the aforesaid operations referred to
in this paragraph, regardless of whether or not CITY has prepared, supplied, or
approved of plans and/or specifications for the subdivision, or regardless of
whether or not such insurance policies~,~'~",~,,, have been determined to be
applicable to any of such damages or claims for damages.
3) Desiqn Defect. If, in the opinion of'the CITY, a design defect in the
work of improvement becomes apparent during the course of construction, or
within one (1) year following acceptance by the CITY of the improvements, and
said design defect, in the opinion of the CITY, may substantially impair the
public health and safety, DEVELOPER shall, upon order by the CITY, correct
said design defect at his sole cost and expense, and the sureties under the
Faithful Performance and Labor and Materials Bonds shall be liable to the CITY
for the corrective work required.
4) Litigation Expenses. In the event that legal action is instituted by
either party to this Agreement, and said action seeks damages for breach of
this Agreement or seeks to specifically enforce the terms of this Agreement,
and, in the event judgment is entered in said action, the prevailing party shall be
entitled to recover its attorneys' fees and court costs. If CITY is the prevailing
party, CITY shall also be entitled to recover its attorney's fees and costs in any
action against DEVELOPER's surety on the bonds provided under paragraph 3.
15. Recitals.
The foregoing Recitals are true and correct and are made a part hereof.
IN WITNESS WHEREOF, the parties hereto have executed this Agreement in
duplicate at Dublin, California, the day and yearfirst above written.
CITY OF DUBLIN
By:
Mayor
ATTEST:
CITY Clerk
DEVELOPER
TKo o~"P"rin{ N"~rne
G:\DEVELOP\Dublin Ranch'C. rea A'¢, 2-5 Tracts 713740\Improvement Agreement Tract 7137.doc
CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT
State of California
County of Contra Costa / ss.
On ?'~5°6~ beforeme, Theresa E. MacNeil-Fog c
Date Name and 3311e of Officer [e.g., 'Jane Doe, Notary Public')
personally appeared ~ -OO Y~ ~V D ~ Y ~' ...'
Name{s) o¢ Signer(s)
~rsonally known to me
~ proved to me on the basis of satisfactow
evidence
to be the person~) whose name~) is/~
subscribed to the within instrument and
acknowledged to me that he/~e/t~y executed
the same in his/~r/th~ir authorized
~¢~~ capacity(i~, and that by his/h~/t¢ir
['~.~ ~~1265741 ~ signature¢ on the instrument the person¢), or
~~~ UOTARY PU~LiC-CAL~FOR~IA ~ the entity upon behalf of which the person~
~~/CONTRA COSTA COUNTY ~ acted, executed the instrument.
WlT~ESS my h~nd,and offical seal.
S gna u e of Nota~ Public
OPTIONAL
Though the information be/ow is not required by law, it may prove valuable to persons relying on the document and coutd prevent
fraudulent removal and reattachment of this form to another document.
Description of Attached Document ~
Title or Type of Document: ~-~ 7'~u~l~'~ TXCL~ 7/D2'7 ~.~.
Document Date: ..... Number of Pages:
Signer(s) Other Than Named Above:
Capacity(les) Claimed by Signer
Signer's Name: ~
[] Individual Top of thumb here
[] Corporate Officer-- Title(s):
[] Partner--[] Limited Iq. General
[] Attorney-in-Fact
[] Trustee
[] Guardian or Conservator
_..% Other:
Signer Is Representing:.
1999 National Notar'j Association * 9350 De Soto Ave., P.O. Box 2402 · Chatswodh. CA 91313-2402 · w~,,,.natJonalnota~j, erg Prod. No. 5907 Reorder. Call Toll-Free 1-800-876-6827
RESOLUTION NO. - 04
A RESOLUTION OF THE CITY COUNCIL
OF THE CITY OF DUBLIN
APPROVING FINAL MAP FOR TRACT 7138
(DUBLIN RANCH AREA A-3, TOLL CA II, LP)
WHEREAS, the Final Map for Tract 7138, in the incorporated territory of the City of Dublin, State
of California, has been presented to this City Council for approval, all in accordance with provisions of
the Subdivision Map Act of the State of California and the City of Dublin Municipal Code; and
WHEREAS, the Developer, Toll CA II, LP, has executed and filed with the City of Dublin a Tract
Improvement Agreement to improve required subdivision improvements in accordance with the
Conditions of Approval for the Tentative Map, and the improvement plans attached thereto; and
WHEREAS, said Tract Improvement Agreement is secured by two bonds furnished by the
Travelers Casualty and Surety Company in the amounts of $506,090.00 (Bond No.103938731), and
$90,000.00 (Bond No.103964606), for a total bond amount of $596,090.00 for the tract drainage and
street improvements, conditioned upon faithful performance of said Agreement; and
WHEREAS, said Tract Improvement Agreement is secured by two bonds furnished by the
Travelers Casualty and Surety Company in the amounts of $506,090.00 (Bond No.103938731), and
$90,000.00 (Bond No.103964606), for a' total bond amount of $596,090.00 for the tract drainage and
street improvements, conditioned upon payment for labor performed or material furnished under the terms
of said Agreement;
NOW, THEREFORE, BE IT RESOLVED that said agreement and bonds are hereby approved.
BE IT FURTHER RESOLVED that the Final Map of Tract 7138 be and the same is hereby
approved, and that rights to the areas marked as West Sugar Hill Terrace, hmisbrook Place, Eaglebrook
Circle, Hazeltine Lane, Blairmore Place, Storm Drain Easement (S.D.E.), Public Service Easement
(P.S.E.), and Public Access Easement (P.A.E.), offered for dedication to public use in conformity with
the terms of dedication be, and they are hereby accepted, subject to improvement} and that the Clerk of
this City Council is hereby directed to transmit said Map to the County Recorder for filing.
PASSED, APPROVED AND ADOPTED this 3rd day of February, 2004.
AYES:
NOES:
ABSENT:
ABSTAIN:
ATTEST: Mayor
City Clerk
g:\develop\dublin ranch\area a~a 2-5 tracts 7137-40~reso fm tract 7138.doc
EXHIBIT "A" TO RESOLUTION - 04
CITY OF DUBLIN
TRACT IMPROVEMENT AGREEMENT
This agreement is made and entered into this 3rd day of February, 2004, by and
between the CITY of Dublin, a municipal corporation, hereinafter referred to as "CITY", and
Toll Ca II, L.P., a California limited partnership, hereinafter referred to as "DEVELOPER".
RECITALS
WHEREAS, it has been determined by the CITY Council of the CITY of Dublin, State
of California, that the DEVELOPER of Tract 7138, desires to improve and dedicate those
public improvements (hereafter "The Improvements") required by City of Dublin Planning
Commission Resolution No. 02-11adopted on February 26, 2002 in accordance with the
requirements and conditions set forth in said resolution, the requirements of the Subdivision
Map Act of the State of California, the Subdivision Ordinance of the CITY, and those certain
plans and specifications for said development entitled Plans' for the Improvement of Dublin
Ranch Area A3 - Tract 7138, prepared by MacKay & Somps and approved by the CITY
on July 11, 2003, and now on file in the office of City Engineer, which are hereby referred to
for a more definite and distinct description of the work to be performed under this Agreement
as though set forth at length herein; and
WHEREAS, DEVELOPER intends to satisfactorily complete The Improvements within
the time hereinafter specified, and CITY intends to accept DEVELOPER's offer(s) of
dedication of The Improvements in consideration for DEVELOPER's satisfactory performance
of the terms and conditions of this Agreement:
NOW, THEREFORE, in consideration of the mutual promises, conditions and
covenants herein contained, the parties agree as follows:
1. Completion Time.
DEVELOPER will commence construction of The Improvements within thirty (30) days
following the date on which CITY executes this Agreement. DEVELOPER shall complete
said work not later than five hundred and fifty (550) days following said date of execution.
Time is of the essence in this Agreement. Upon completion, DEVELOPER shall furnish CITY
with a complete and reproducible set of final as-built plans of The Improvements, including
any authorized modifications.
2. Estimated Cost of Improvements.
The estimated cost of constructing The Improvements required by this agreement as
presented in the Bond Estimate for Tract 7138, dated iViarch 27, 2003 prepared by
MacKay and Somps is agreed to be $596,090.00. Said amount includes costs and
reasonable expenses and fees which may be incurred in enforcing the obligation secured.
3. Bonds Furnished.
Concurrently with the execution of this Agreement, DEVELOPER shall furnish CITY
with the following security in a form satisfactow to the CITY Attorney:
A. Faithful Performance. Either a cash deposit, a corporate surety bond issued
by a company duly and legally licensed to conduct a general surety business in the State of
California, or an instrument of credit equivalent to one hundred per cent (100%) of the
estimate set forth in Paragraph 2 and sufficient to assure CITY that The Improvements will be
satisfactorily completed.
B. Labor and Materials. Either a cash deposit, a corporate surety bond issued
by a company duly and legally licensed to conduct a general surety business in the State of
California, Or an instrument of credit equivalent to one-hundred per cent (100%) of the
estimate set forth in Paragraph 2 and sufficient to assure CITY that DEVELOPER'S
contractors, subcontractors, and other persons furnishing labor, materials, or equipment
shall be paid therefor.
C. If required by CITY, a cash deposit, corporate surety bond, or instrument of
credit sufficient to assure CITY that the surface water drainage of the subdivision shall not
interfere with the use of neighboring property, including public streets and highways.
CITY shall be the sole indemnitee named.on any instrument required by this
Agreement. Any instrument or deposit required herein shall conform with the provisions of
Chapter 5 of the Subdivision Map Act.
4. Insurance Required.
Concurrently with the execution hereof, DEVELOPER shall obtain or cause to be
obtained and filed with the CITY, all insurance required under this paragraph, and such
insurance shall have been approved by the Administrative Services Director of CITY, or his
designee, as to form, amount and carrier. Prior to the commencement of work under this
Agreement, DEVELOPER's general contractor shall obtain or cause to be obtained and filed
with the Administrative Services Director, all insurance required under this paragraph, and
such insurance shall have been approved by the .Administrative Services Director of CITY, as
to form, amount and carrier. DEVELOPER shall not alloW any contractor or subcontractor to
commence work on this contract or subcontract until all insurance required for DEVELOPER
and DEVELOPER's general contractor shall have been so obtained and approved. Said
insurance shall be maintained in full force and effect until the completion of work under this
Agreement and the final acceptance thereof by CITY. All requirements herein provided shall
appear either in the body of the insurance policies or as endorsements and shall specifically
bind the insurance carder,
A. Minimum Scope of insurance. Coverage shaii be at least as broad as:
1) Insurance Services Office form number GL 0002 (Ed. 1/73) covering
comprehensive General Liability and Insurance Services Office form number
GL 0404 covering Broad Form Comprehensive General Liability; or Insurance
Services Office Commercial General Liability coverage ("occurrence" form
CG 0001 .)
2) Insurance Services Office form number CA 0001 (Ed. 1/78) covering
Automobile Liability, code 1 "any auto" and endorsement CA 0025.
3) Workers' Compensation insurance as required by the Labor Code of the
State of California and Employers Liability Insurance.
B. Minimum Limits of Insurance. DEVELOPER shall maintain limits no less
than:
1 ) General Liability: $1,000,000 combined single limit per occurrence for
bodily injury, personal injury and property damage. If commercial General
Liability Insurance or other form with a general aggregate limit is used, either
the general aggregate limit shall apply separately to this project/location or the
general aggregate limit shall be twice the required occurrence limit.
2) Automobile Liability.: $1,000,000 combined single limit per accident for
bodily injury and property damage.
3) Workers' Compensation and Employers Liability: Workers'
compensation limits as required by the Labor Code of the State of California
and Employers Liability limits of $1,000,000 per accident.
C. Deductibles and Self-Insurance. Retentions. Any deductibles or self-
insured retentions must be declared to and approved by the CITY. At the option of the
CITY, either the insurer shall reduce or eliminate such deductibles or self-insured
retentions as respects the CITY, its officers, officials and employees; or the
DEVELOPER shall procure a bond guaranteeing payment of losses and related
investigations, claim administration and defense expenses.
D. Other Insurance Provisions. The policies are to contain, or be endorsed to
contain, the following provisions:
1) General Liability and Automobile Liability Coverages.
a) The CITY, its officers, agents, officials, employees and volunteers
shall be named as additional insureds as respects: liability arising
out of activities performed by or on behalf of the DEVELOPER;
products and completed operations of the DEVELOPER;
premises owned, occupied or used by the DEVELOPER; or
automobiles owned, leased, hired or borrowed by the
DEVELOPER. The coverage shall contain no special limitations
on the scope of the protection afforded to the CITY, its officers,
officials, employees or volunteers.
b) The DEVELOPER's insurance coverage shall be primary
insurance as respects the CITY, its officers, officials, employees
and volunteers. Any insurance or self-insurance maintained by
the CITY, its officers, officials, employees or volunteers shall be
excess of the DEVELOPER's insurance and shall not contribute
with it.
c) Any failure to comply with reporting provisions of the policies shall
not affect coverage provided to the CITY, its officers, officials,
employees or volunteers.
d) The DEVELOPER's insurance shall apply separately to each
insured against whom claim is made or suit is brought, except with
respect to the limits of the insurer's liability.
2) Workers' Compensation and Employers Liability Coverage.
The insurer shall agree to waive all rights of subrogation against the
CITY, its officers, officials, employees and volunteers for losses arising from
work performed by the DEVELOPER for the CITY.
3) All Coverages.
Each insurance policy required by this clause shall be endorsed to state
that coverage shall not be suspended, voided, cancelled by either party, reduced in
coverage or in limits except after thirty (30) days' prior written notice by certified mail,
return receipt requested, has been given to the CITY.
a) Acceptability of Insurers. Insurance is to be placed with insurers
with a Bests' rating of no less than A:Vll.
b) Verification of Coveraqe. DEVELOPER shall furnish CITY with
certificates of insurance and with original endorsements effecting
coverage required by this clause. The certificates and
endorsements for each insurance policy are to be signed by a
person authorized by that insurer to bind coverage on its behalf.
The certificates and endorsements are to be received and
approved by the CITY before work commences. The CITY
reserves the right to require complete, certified copies of all
required insurance policies, at any time.
c) Subcontractors. DEVELOPER and/or DEVELOPER's general
contractor shall include ali subcontractors as insureds under its
policies or shall obtain separate certificates and endorsements for
each subcontractor. All coverages for subcontractors shall be
subject to all of the requirements stated herein.
5. Work Performance and Guarantee.
Except as otherwise expressly provided in this Agreement, and excepting only items of
routine maintenance, ordinary wear and tear and unusual abuse or neglect, DEVELOPER
guarantees all work executed by DEVELOPER and/or DEVELOPER's agents, and all
supplies, materials and devices of whatsoever nature incorporated in, or attached to the
work, or otherwise delivered to CITY as a part of the work pursuant to the Agreement, to be
free of all defects of workmanship and materials for a period of one (1) year after initial
acceptance of the entire work by CITY. DEVELOPER shall repair or replace any or all such
work or material, together with all or any other work or materials which may be displaced or
damaged in so doing, that may prove defective in workmanship or material within said one-
year guarantee period without expense or charge of any natUre whatsoever to CITY.
DEVELOPER further covenants and agrees that when defects in design, workmanship and
materials actually appear during the one-year guarantee period, and have been corrected,
the guarantee period shall automatically be extended for an additional year to insure that
such defects have actually been corrected.
In the event the DEVELOPER shall fail to comply with the conditions of the foregoing
guarantee within thirty (30) days time, after being notified of the defect in writing, CITY'shall
have the right, but shall not be obligated, to repair or obtain the repair of the defect, and
DEVELOPER shall pay to CITY on demand all costs and expense of such repair.
Notwithstanding anything herein to the contrary, in the event that any defect in workmanship
or material covered by the foregoing guarantee results in a condition which constitutes an
immediate hazard to the public health, safety, or welfare, CITY shall have the right to
immediately repair, or cause to be repaired, such defect, and DEVELOPER shall pay to CITY
on demand all costs and expense of Such repair. The foregoing statement relating .to
hazards to health and safety shall be deemed to include either temporary or permanent
repairs which may be required as determined in the sole discretion and judgment of CITY.
If CITY, at its sole option, makes or causes to be made the necessary repairs or
replacements or performs the necessary work, DEVELOPER shall pay, in addition to actual
costs and expenses of such repair or work, fifty percent (50%) of such costs and expenses
for overhead and interest atthe maximum rate of interest permitted by law accruing thirty (30)
days from the date of billing for such work or repairs.
6. Inspection of the Work.
DEVELOPER shall guarantee free access to CITY through its Public Works
Director/City Engineer and his designated representative for the safe and convenient
inspection of the work throughout its construction. Said CITY representative shall have the
authority to reject all materials and workmanship which are not in accordance with the plans
and specifications, and all such materials and or work shall be removed promptly by
DEVELOPER and replaced to the satisfaction of CITY without any expense to CITY in strict
accordance with the improvement plans and specifications.
7. Agreement Assiqnment.
This Agreement shall not be assigned by DEVELOPER without the written consent of
CITY.
8. Abandonment of Work.
Neither DEVELOPER nor any of DEVELOPER's agents or contractors are or shall be
considered to be agents of CITY in connection with the performance of DEVELOPER's
obligations under this Agreement.
If DEVELOPER refuses or fails to obtain prosecution of the work, or any severable
part thereof, with such diligence as will insure its completion within the time Specified, or any
extension thereof, or fails to obtain completion of said work within such time, or if
DEVELOPER should be adjudged as bankrupt, or should make a general assignment for the
benefit of DEVELOPER's creditors, or if a receiver should be appointed, or if DEVELOPER,
or any of DEVELOPER's contractors, subcontractors, agents or employees should violate
any of the provisions of this Agreement, the CITY through its Public Works Director may
serve written notice on DEVELOPER and DEVELOPER's surety or holder of other security of
breach of this Agreement, or of any portion, thereof, and default of DEVELOPER.
In the event of any such notice of breach of this Agreement, DEVELOPER's surety
shall have the duty to take over and complete The Improvements herein specified; provided,
however, that if the surety, within thirty (30) days after the serving upon itof such notice of
breach, does not give CITY written notice of its intention to take over the performance of the
contract, and does not commence performance thereof within thirty (30) days after notice to
CITY of such election, CITY may take over the work and prosecute the same to completion,
by contract or by any other method CITY may deem advisable, for the account and at the
expense of DEVELOPER and DEVELOPER's surety shall be liable to CITY for any damages
and/or reasonable and documented excess costs occasioned by CITY thereby; and, in such
event, CITY, without liability for so doing, may take possession of, and utilize in completing
the work, such materials, appliances, plant and other property belonging to DEVELOPER as
may be on the site of the work and necessary therefor.
All notices herein required shall be in writing, and delivered in person or sent by
registered mail, postage prepaid.
Notices required to be given to CITY shall be addressed as follows:
City Manager
City of Dublin
100 Civic Plaza
Dublin, CA 94568
Notices required to be given to DEVELOPER shall be addressed as follows:
Toll Brothers, lnc
100 Park Place, Suite I
San Ramon, CA 94583
Notices required to be given surety of DEVELOPER shall be addressed as follows:
Toll Brothers, Inc
100 Park Place, Suite 140
San Ramon, CA 94583
Any party or the surety may change such address by notice in writing to the other party
and thereafter notices shall be addressed and transmitted to the new address.
Concurrently with the execution of this Agreement, DEVELOPER has executed and
has caused to be acknowledged an abstract of this Agreement. DEVELOPER agrees CITY
may record said abstract in the Official Records of Alameda County.
9. Use of Streets or Improvements.
At all times prior to the final acceptance of the Work by CITY, the use of any or all
streets and improvements within: the work to be performed under this Agreement shall be at
the sole and exclusive risk of DEVELOPER. The issuance of any building or occupancy
permit by CITY for dwellings' located within the tract shall not be construed in anymanner to
constitute a partial or final acceptance or approval of any or all' such improvements by CITY.
DEVELOPER agrees that CITY's Building Official may withhold the issuance of building or
occupancy permits when the work or its progress may substantially and/or detrimentally
affect public health and safety.
10. Safety Devices.
DEVELOPER shall provide and maintain such guards, watchmen, fences, barriers,
regulatory signs, warning lights, and other safety devices adjacent to and o.n the tract site as
may be necessary to prevent accidents to the public and damage to the property.
DEVELOPER shall furnish, place, and maintain such lights as may be necessary for
illuminating the said fences, barriers, signs, and other safety devices. At the end of all work
to be performed under this Agreement, all fences, barriers, regulatory signs, warning lights,
and other safety devices (except such safety items as may be shown on the plans and
included in the items of work) shall be removed from site of the work by the DEVELOPER,
and the entire site left clean and orderly.
11. Acceptance of Work.
Upon notice of the completion of all tract work andrthe delivery of a set of final as-built
plans to CITY by DEVELOPER, CITY, through its City Engineer or his designated
representative, shall examine the tract work without delay, and, if found to be in accordance
with said plans and specifications and this Agreement, shall recommend acceptance of the
work to the City Council and, upon such acceptance, shall notify DEVELOPER or his
designated agents of such acceptance.
12. Patent and Copyright Costs.
In the event that said plans and specifications require the use of any material, process
or publication which is subject to a duly registered patent or copyright, DEVELOPER shall be
liable for, and shall indemnify CITY from any fees, costs or litigation expenses, including
attorneys' fees and court costs, which may result from the use of said patented or copyrighted
material, process or publication.
13. Alterations in Plans and Specifications.
Any alteration or alterations made in the plans and specifications which are a part of
this Agreement or any provision of this Agreement shall not operate to release any surety or
sureties from liability on any bond or bonds attached hereto and made a part hereof, and
consent to make such alterations is hereby given, and the sureties to said bonds hereby
waive the provisions of Section 2819 of the Civil Code of. the State of California.
14. Liability.
A. DEVELOPER Primarily Liable. DEVELOPER hereby warrants that the
design and construction of. The Improvements will not adversely affect any portion of
adjacent properties and that all Work will be performed in a proper manner.
DEVELOPER agrees to indemnify, defend, release, and save harmless CITY, and
each of its elective and appointive boards, commissions, officers agents and
.employees, from and against any and all loss, claims, suits, liabilities, actions,
damages, or causes of action of every kind, nature and description, directly or
indirectly arising from an act or omission of DEVELOPER, its employees, agents, or
independent contractors in connection with DEVELOPER'S actions and obligations
hereunder; provided as follows:
1) That CITY does not, and shall not, waive any rights against
DEVELOPER which it may have by reason of the aforesaid hold harmless
agreement, because of the acceptance by CITY, or the deposit with CITY by
DEVELOPER, of any of the insurance policies described in Paragraph 4 hereof.
2) That the aforesaid hold harmless agreement by DEVELOPER shall
apply to all damages and claims for damages of every kind suffered, or alleged
to have been suffered, by reason of any of the aforesaid operations referred to
in this paragraph, regardless of whether or not CITY has PrePared, supplied, or
approved of plans and/or specifications for the subdivision, or regardless of
whether or not such insurance policies shall have been determined to be
applicable to any of such damages or claims for damages.
3) Desi.qn Defect. If, in the opinion of the CITY, a design defect in the
work of. improvement becomes apparent during the course of construction, or
CALIFORNIA ALL.-PURPOSE ACKNOWLEDGMENT
State of California '~
County of Contra Costa ~ ss.
On ~' ~ 9' 6 ~ before me. Theresa E. MacNeil-Fogelman,Notary ,Pub] c
Name(s} of Signer(s)
~personally known to me
[] proved to me on the basis of satisfactory
evidence
to be the person,C) whose name,~) is/a~
subscribed to the within instrument and
acknowledged to me that he/s~,e/t!)ey executed
the same in his/l~r/t~jCir authorized
capacity(ie~, and that by his/h.~/!f~ir
signature~ on the instrument the person.C), or
the entity upon behalf of which the person~'~
acted, executed the instrument.
WITNESS my hand. and official seal~ ~
OPTIONAL
Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent
fraudulent removal and reattachment of this form to another document.
Description of Attached Document
Title or Type of Document: %'~/~(/~
Document Date: Number of Pages:
Signer(s) Other Than Named Above:
Capacity(ies) Claimed by Signer
Signer's Name:
[] Individual Top of thumb here
[] Corporate Officer -- Title(s):
[] Partner- [] Limited "q General
[] Attorney-in-Fact
[] Trustee
[] Guardian or Conservator
[] Other:.
Signer is Representing:.
1999 National Notary Aseociatk~n · 9350 De Soto Ave., P.O. Box 2402 * Chatsworth, CA 91313-2402 · www. nationalnota ~,.o r g Prod. No. 5907 Reorder, Call Toll-Free 1-800-876-6827
within one (1)year following acceptance by the CITY of the improvements, and
said design defect, in the opinion of the CITY, may substantially impair the
public health and safety, DEVELOPER shall, upon order by the CITY, correct
said design defect at his sole cost and expense, and the sureties under the
Faithful Performance and Labor and Materials Bonds shall be liable to the CITY
for the corrective work required.
4) Litigation Expenses. In the event that legal action is institUted by
either party to this Agreement, and said action seeks damages for breach of
this Agreement or seeks to specifically enforce the terms of this Agreement,
and, in the event judgment is entered in said action, the prevailing party shall be
entitled to recover its attorneys' fees and court costs. If CITY is the prevailing
party, CITY shall also be entitled to recover its attorney's fees and costs in any
action against DEVELOPER's surety on the bonds provided under paragraph $.
15. Recitals.
The foregoing Recitals are true and correct and are made a part hereof.
IN WITNESS WHEREOF, the parties hereto have executed this Agreement in
duplicate at Dublin, California, the day and year first above written.
CITY OF DUBLIN
By:
Mayor
ATTEST:
CITY Clerk
DEVELOPER
Type or Print Name
Title
G:\DEVELOP\Dublin Ranch~Area A~A 2-5 Tracts 7137-40\Improvement Agreement Tract 7158.doc
RESOLUTION NO. - 04
A RESOLUTION OF THE CITY COUNCIL
OF THE CITY OF DUBLIN
ACCEPTANCE OF IN LIEU PARKLAND DEDICATION FEES AND CREDITS
FOR TRACTS 7137 & 7138
WHEREAS, pursuant to Section 8-7.1 of the Subdivision Ordinance 1-91, as adopted by the City of
Dublin, and City of Dublin Municipal Code 9.28.020, as amended by City Council Resolution 60-99, each
subdivider of land for residential uses shall as a condition of the approval of a Final Subdivision Map,
dedicate or reserve lands, pay fees in lieu thereof, or a combination of both, for park and/or recreational
purposes; and
WHEREAS, in Resolution 02-10 for Tentative Map Tract 7137 and Resolution 02-11 for Tentative
Map Tract 7138 adopted on February 26, 2002, the Planning Commission did determine in accordance with
the aforesaid Subdivision Ordinance that a land dedication for park and recreational facilities is to be made,
and said dedication is to be used for the development of park and recreational facilities within a period of five
years from the date of adoption of this resolution to serve the residents of the subject tracts; and
WHEREAS, pursuant to Development Agreements adopted by the City as Ordinance No. 13-03 for
Dublin Ranch Area A2 and A3 (Tracts 7137 and 7138), the developer (Toll CA II, LP) can utilize the credits
granted to the Lin Family according to the Master Development Agreement between the' Lin Family and the
City recorded as Series No. 99-251790 on July 8, 1999, against the applicable portions of the City's Public
Facility Fee relating to Community Park Land; and
WHEREAS, an "Authorization to Use Eastern Dublin Public Facility Impact Fee Credits" Agreement
has been executed between the Lin Family and Toll CA II, LP, to transfer 1.501 acres of Community Park
Land credits pursuant to the Lin Family Master Development Agreement to Toll CA II, LP; and
WHEREAS, Toll CA II, LP, has paid to the City an in lieu fee in the amount of $456,806.00 which
satisfies the 0.643-acre requirement for the Neighborhood Park Land component of the Public Facility Fee for
Low Density Residential Units in Eastern Dublin for Tracts 7137 and 7138;
NOW, THEREFORE, BE IT RESOLVED that the aforesaid in lieu fee and credits are hereby
accepted as performance of said subdivider's obligation under Section 8-7.1 et seq. of the aforesaid
Subdivision Ordinance 97-1.
PASSED, APPROVED AND ADOPTED this 3rd day of February, 2004.
AYES:
NOES:
ABSENT:
ABSTAIN:
ATTEST: Mayor
City Clerk