HomeMy WebLinkAboutReso 122-10 Positano Tr Improv Agmt C-1RESOLUTION NO. 122 -10
A RESOLUTION OF THE CITY COUNCIL
OF THE CITY OF DUBLIN
*********
APPROVING FINAL MAP AND TRACT IMPROVEMENT AGREEMENT
FOR TRACT 8036, NEIGHBORHOOD C-1, POSITANO/ FALLON VILLAGE
WHEREAS, the Final Map for Tract 8036, in the incorporated territory of the City of
Dublin, State of California, has been presented to this City Council for approval, all in
accordance with provisions of the Subdivision Map Act of the State of California and the City of
Dublin Municipal Code; and
WHEREAS, the Developer, K. Hovnanian at Positano LLC, a California Limited Liability
Company, has executed and filed with the City of Dublin a Tract Improvement Agreement for
Tract 8036 to improve required subdivision improvements in accordance with the Conditions of
Approval for the Tentative Map, and with the improvement plans attached thereto; and
WHEREAS, said Tract Improvement Agreement is secured by bonds furnished by the
Bond Safeguard Insurance Corporation in the amount of $1,638,410 for the in-tract
improvements (Bond No. 5037667), conditioned upon faithful performance of said Agreement;
and
WHEREAS, said Tract Improvement Agreement is secured by bonds furnished by the
Bond Safeguard Insurance Company in the amount of $1,638,410 for the in-tract improvements
(Bond No. 5037667), conditioned upon payment for labor perFormed or material furnished under
the terms of said Agreement.
NOW, THEREFORE, BE IT RESOLVED that said agreement and bonds are hereby
approved.
BE IT FURTHER RESOLVED that the City Manager of the City of Dublin is hereby
authorized to execute said Tract Improvement Agreement, attached hereto as Exhibit A.
BE IT FURTHER RESOLVED that the Final Map of Tract 8036 be and the same is
hereby approved, and that rights to the areas marked as Amantea Way, Cipriani Way, Ravello
Way, Salerno Drive, and Public Service Easement (PSE), offered for dedication to public use in
conformity with the terms of dedication be, and they are hereby accepted, subject to
improvement, and that the Clerk of this City Council is hereby directed to transmit said Map to
the County Recorder for filing.
Page 1 of 2
PASSED, APPROVED AND ADOPTED this 17th day of August, 2010 by the following vote:
AYES: Councilmembers Biddle, Hart, Hildenbrand, Scholz, and Mayor Sbranti
NOES: None
ABSENT: None
ABSTAIN: None
~,~.-..-
.~c9-~~
ATTEST:
Mayor
~ ~ `~
~~ / ~~
City Clerk
Reso No. 12210, Adopted 8-17-10, Item 4.10 Page 2 of 2
~~ a~
~
CITY OF DUBLIN
IMPROVEMENT AGREEMENT
Tract 8036, Neighborhood "C-1",
Positano/ Fallon Village
This agreement is made and entered into this 17th day of August, 2010, by and
between the City of Dublin, a municipal corporation, hereinafter referred to as "CITY", and
K. Hovnanian at Positano LLC, a California Limited Liability Company, hereinafter referred to
as "DEVELOPER".
RECITALS
WHEREAS, it has been determined by the CITY Council of the CITY of Dublin, State
of California, that DEVELOPER, the subdivider of Tract 8036, also known as Positano/ Fallon
Village Neighborhood "C-1", desires to improve and dedicate those public improvements
(hereafter "The Improvements") in accordance with the requirements and conditions set forth
in the City of Dublin Planning Commission Resolution No. 05-61 (PA 05-038), adopted on
November 22, 2005, and City Council Resolution No. 223-05, adopted on December 6,
2005 ;the requirements of the Subdivision Map Act of the State of California, the Subdivision
Ordinance of the CITY, and those certain plan and specifications for said development
approved by the City Engineer, as follows:
• "lmprovement Plans , Tract 7855, 8036 and 8037 - Fallon Village, Neigh,borhood C';
(29 Sheets, Sheets 1-29), prepared by MacKay and Somps, Inc, approved April 14,
2010
• "Joint Trench Composite, Fal/on Village C9 (3 Sheets, Sheets JT1-JT3), prepared by
Millenium Design and Construction, Inc, approved July 2010
•"Street Lighting, Fallon Village C9 (4 Sheets, Sheets SL1-SL4), prepared by Millenium
Design and Construction, Inc, approved Jul y 2010
• "Positano Neighborhood C Landscaping'; (31 Sheets, Sheets L0.1-L4.1), prepared by
Gates and Associates, approved July 2010
WHEREAS, DEVELOPER intends to satisfactorily complete The Improvements within
the time hereinafter specified, and CITY intends to accept DEVELOPER's offer(s) of
dedication of The Improvements in consideration for DEVELOPER's satisfactory pertormance
of the terms and conditions of this Agreement; and
WHEREAS, CITY has determined that The Improvements are a public works subject
to Cafifornia prevailing wage requirements:
EXHIBIT
~.
To the Resolution
$~ ~
~
NOW, THEREFORE, in consideration of the mutua! promises, conditions and
covenants herein contained, the parties agree as follows:
1. Completion Time.
DEVELOPER will commence construction of The Improvements within thirty (30) days
following the date on which CITY executes this agreement. DEVELOPER shall complete
said work not later than two years following said date of execution of this agreement, unless
the completion date is extended by the City Council. Time is of the essence in this
Agreement. Upon completion, DEVELOPER shall furnish CITY with a complete and
reproducible set of final as-built plans of The Improvements, including any authorized
modifications.
2. Estimated Cost of Improvements.
The estimated cost of constructing The Improvements required by this agreement is
agreed to be as presented in the Bond Estimate - Fallon Village - Neighborhood C1, dated
April 2010 prepared by MacKay & Somps ($1,638,410), and within the limits shown on the
Fallon Village Neighborhood C and La Strada Drive - Positano Final Map and Bonding Key,
attached to this agreement as Exhibits "A" and "B". Said amount includes costs and
reasonable expenses and fees which may be incurred in enforcing the obligation secured.
3. Bonds Furnished.
Concurrently with the execution of this Agreement, DEVELOPER shall furnish CITY
with the Fo(lowing security in a form satisfactory to the City Attorney:
A. Faithful Performance. Either a cash deposit, a corporate surety bond issued
by a company duly and legally licensed to conduct a general surety business in the State of
California, or an instrument of credit equivalent to one hundred per cent (100%) of the
estimate set forth in Paragraph 2 and sufficient to assure CITY that The Improvements will be
satisfactorily completed.
B. Labor and Materials. Either a cash deposit, a corporate surety bond issued
by a company duly and legally licensed to conduct a general surety business in the State of
California, or an instrument of credit equivalent to one-hundred per cent (100%) of the
estimate set forth in Paragraph 2 and sufficient to assure CITY that DEVELOPER'S
contractors, subcontractors, and other persons furnishing labor, materials, or equipment shall
be paid therefor.
C. If required by CITY, a cash deposit, corporate surety bond, or instrument of
credit sufficient to assure CITY that the surFace water drainage of the subdivision shall not
interFere with the use of neighboring property, including public streets and highways.
b a~
C1TY shall be the sole indemnitee named on any instrument required by this
Agreement. Any instrument or deposit required herein shall conform to the provisions of
Chapter 5 of the Subdivision Map Act.
3. Insurance Required.
Prior to commencing construction of the improvements, DEVELOPER shall obtain or
cause to be obtained and filed with the CITY, all insurance required under this paragraph
Prior to the commencement of work under this Agreement, DEVELOPER's general contractor
shall obtain or cause to be obtained and filed with the Administrative Services Director, all
insurance required under this paragraph DEVELOPER shall not allow any contractor or
subcontractor to commence work on this contract or subcontract until all insurance required
for DEVELOPER and DEVELOPER's general contractor shall have been so obtained and
approved. Said insurance shall be maintained in full force and effect until the completion of
work under this Agreement and the final acceptance thereof by CITY. All requirements
herein provided shall appear either in the body of the insurance policies or as endorsements
and shall specifically bind the insurance carrier.
A. Minimum Scope of Insurance. Coverage shall be at least as broad as:
1) Insurance Services Office form number GL 0002 (Ed. 1/73) covering
comprehensive General Liabilitv and Insurance Services Office form number
GL 0404 covering Broad Form Comprehensive General Liability; or Insurance
Services Office Commercial General Liability coverage ("occurrence" form
CG 0001.)
2) Insurance Services Office form number CA 0001 (Ed. 1/78) covering
Automobile Liability, code 1"any auto" and endorsement CA 0025.
3) Workers' Compensation insurance as required by the Labor Code of the
State of California and Employers Liability Insurance.
B. Minimum Limits of insurance. DEVELOPER shall maintain limits no less
than:
1) General Liabilitv: $1,000,000 combined single limit per occurrence for
bodily injury, personal injury and property damage. If commercial General
Liability Insurance or other form with a general aggregate limit is used, either
the general aggregate limit shall apply separately to this project/location or the
general aggregate limit shall be twice the required occurrence limit.
2) Automobile Liabilitv: $1,000,000 combined single limit per accident for
bodily injury and property damage.
3) Workers' Compensation and Emplovers Liabilitv: Workers'
compensat~on limits as required by the Labor Code of the State of California
and Employers Liability limits of $1,000,000 per accident.
~o~ a~
C. Deductibles and Self-Insurance Retentions. Any deductibles or self-
insured retentions must be declared to and approved by the CITY. At the option of the
CITY, DEVELOPER shall procure a bond guaranteeing payment of losses and related
investigations, claim administration and defense expenses.
D. Other Insurance Provisions. The policies are to contain, or be endorsed to
contain, the following provisions:
1) General Liabilitv and Automobile Liability Coveraqes.
a) The CITY, its officers, agents, officials, employees and volunteers
shall be named as additional insureds as respects: liability arising
out of activities performed by or on behalf of the DEVELOPER;
products and completed operations of the DEVELOPER;
premises owned, occupied or used by the DEVELOPER; or
automobiles owned, leased, hired or borrowed by the
DEVELOPER. The coverage shall contain no special limitations
on the scope of the protection afforded to the CITY, its officers,
officials, employees or volunteers.
b) The DEVELOPER's insurance coverage shall be primary
insurance as respects the CITY, its officers, officials, employees
and volunteers. Any insurance or self-insurance maintained by
the CITY, its officers, officials, employees or volunteers shall be
excess of the DEVELOPER's insurance and shall not contribute
with it.
c) Any failure to comply with reporting provisions of the policies shall
not affect coverage provided to the CITY, its officers, officials,
employees or volunteers.
d) The DEVELOPER's insurance shall apply separately to each
insured against whom claim is made or suit is brought, except with
respect to the limits of the insurer's liability.
2) Workers' Compensation and Emplovers Liability Coveraqe.
The insurer shall agree to waive all rights of subrogation against the
CITY, its officers, officials, empfoyees and volunteers for losses arising from
work performed by the DEVELOPER for the CITY_
3) All Coveraqes.
Each insurance policy required by this clause shall be endorsed to state
that coverage shall not be suspended, voided, cancelled by either party, reduced in
coverage or in limits except after thirty (30) days' prior written notice by certified mail,
return receipt requested, fias been given to the CITY.
4
~~~ ag
~
a) Acceptabilitv of Insurers. Insurance is to be placed with insurers
with a Bests' rating of no less than A:VII.
b) Verification of Coveraqe. DEVELOPER shall furnish CITY with
certificates of insurance and with original endorsements effecting
coverage required by this clause. The certificates and
endorsements for each insurance policy are to be signed by a
person authorized by that insurer to bind coverage on its behalf.
The certificates and endorsements are to be received and
approved by the CITY before work commences. The CITY
reserves the right to require complete, certified copies of all
required insurance policies, at any time.
c) Subcontractors. DEVELOPER and/or DEVELOPER's general
contractor shall include all subcontractors as insureds under its
policies or shall obtain separate certificates and endorsements for
each subcontractor. All coverages for subcontractors shall be
subject to all of the requirements stated herein.
4. Work Performance and Guarantee.
Except as otherwise expressly provided in this Agreement, and excepting only items of
roufine maintenance, ordinary wear and tear and unusual abuse or neglect, DEVELOPER
guarantees all work executed by DEVELOPER and/or DEVELOPER's agents, and all
supplies, materials and devices of whatsoever nature incorporated in, or attached to the
work, or otherwise delivered to CITY as a part of the work pursuant to the Agreement, to be
free of all defects of workmanship and materials for a period of one (1) year after initia!
acceptance of the entire work by CITY. DEVELOPER shall repair or replace any or all such
work or material, together with all or any other work or materials which may be displaced or
damaged in so doing, that may prove defective in workmanship or material within said one-
year guarantee period without expense or charge of any nature whatsoever to CITY.
DEVELOPER further covenants and agrees that when defects in design, workmanship and
materials actually appear during the one-year guarantee period, and have been corrected,
the guarantee period shall automatically be extended for an additional year [HOLD]to insure
that such defects have actually been corrected.
In the event the DEVELOPER shall fail to comply with the conditions of the foregoing
guarantee within thirty (30) days time, after being notified of the defect in writing, CITY shall
have the right, but shall not be obligated, to repair or obtain the repair of the defect, and
DEVELOPER shall pay to CITY on demand all costs and expense of such repair.
Notwithstanding anything herein to the contrary, in the event that any defect in workmanship
or material covered by the foregoing guarantee results in a condition which constitutes an
immediate hazard to the public health, safety, or welfare, CITY shall have the right to
immediately repair, or cause to be repaired, such defect, and DEVELOPER shall pay to CITY
on demand all costs and expense of such repair. The foregoing statement relating to
la ~~a~-
hazards to health and safety shall be deemed to include either temporary or permanent
repairs which may be required as determined in the sole discretion and judgment of CtTY.
If CITY, at its sole option, makes or causes to be made the necessary repairs or
replacements or performs the necessary work, DEVELOPER shall pay, in addition to actual
costs and expenses of such repair or work, fifty percent (50%) of such costs and expenses
for overhead and interest at the maximum rate of interest permitted by law accruing thirty (30)
days from the date of billing for such work or repairs.
5. Inspection of the Work.
DEVELOPER shall guarantee free access to CITY through its City Engineer and
designated representative for the safe and convenient inspection of the work throughout its
construction. Said CITY representative shall have the authority to reject all materials and
workmanship which are not in accordance with the plans and specifications, and all such
materials and or work shall be removed promptly by DEVELOPER and replaced to the
satisfaction of CITY without any expense to CITY in strict accordance with the improvement
plans and specifications.
6. Agreement Assiqnment.
This Agreement shall not be assigned by DEVELOPER without the written consent of
CITY, which shall not be unreasonably withheld, denied, or delayed.
7. Abandonment of Work.
Neither DEVELOPER nor any of DEVELOPER's agents or contractors are or shall be
considered to be agents of CITY in connection with the performance of DEVELOPER's
obligations under this Agreement.
If DEVELOPER refuses or fails to obtain prosecution of the work, or any severable
part thereof, with such diligence as will insure its completion within the time specified, or any
extension thereof, or fails to obtain completion of said work within such time, or if
DEVECOPER should be adjudged as bankrupt, or should make a general assignment for the
benefit of DEVELOPER's creditors, or if a receiver should be appointed, or if DEVELOPER,
or any of DEVELOPER's contractors, subcontractors, agents or employees should violate
any of the provisions of this Agreement, the CITY through its City Engineer may serve written
notice on DEVELOPER and DEVELOPER's surety or holder of other security of breach of
this Agreement, or of any portion, thereof, and default of DEVELOPER.
In the event of any such notice of breach of this Agreement, DEVELOPER's surety
shall have the duty to take over and complete The Improvements herein specified; provided,
however, that if the surety, within thirty (30) days after the serving upon it of such notice of
breach, does not give CITY written notice of its intention to take over the perFormance of the
contract, and does not commence performance thereof within thirty (30) days after notice to
CIIY of such election, CITY may take over the work and prosecute the same to completion,
by contract or by any other method CITY may deem advisable, for the account and at the
~~ a~~
~
expense of DEVELOPER and DEVELOPER's surety shall be liabie to CITY for any damages
and/or reasonable and documented excess costs occasioned by CITY thereby; and, in such
event, CITY, without liability for so doing, may take possession of, and utilize in completing
the work, such materials, appliances, plant and other property belonging to DEVELOPER as
may be on the site of the work and necessary therefor.
All notices herein required shall be in writing, and delivered in person or sent by
registered mail, postage prepaid.
Notices required to be given to CITY shall be addressed as follows:
Mark Lander, City Engineer
City of Dublin
100 Civic Plaza
Dublin, CA 94568
(925)-833-6630
Notices required to be given to DEVELOPER shall be addressed as follows:
Richard Balestreri
Vice President Land Acquisition and Planning
K. Hovnanian Homes, Inc.
Sacramento, CA 95815
(916)- 920-0200
Notices required to be given surety of DEVELOPER shall be addressed as follows:
Bond Safeguard Insurance Company
900 S. Frontage Road, Ste. 250
Woodridge, IL 60517
630-495-9380
Any party or the surety may change such address by notice in writing to the other party
and thereafter notices shall be addressed and transmitted to the new address.
8. Use of Streets or Improvements.
At all times prior to the final acceptance of the work by CITY, the use of any or all
streets and improvements within the work to be perFormed under this Agreement shall be at
the sole and exclusive risk of DEVELOPER. The issuance of any building or occupancy
permit by ClTY for dwellings located within the tract shall not be construed in any manner to
constitute a partial or final acceptance or approva! of any or all such improvements by CITY.
DEVELOPER agrees that CITY's Building Official may withhold the issuance of building or
occupancy permits when the work or its progress may substantialfy and/or detrimentally
affect public health and safety.
I~~ a~~
9. Safetv Devices.
DEVELOPER shall provide and maintain such guards, watchmen, fences, barriers,
regulatory signs, warning lights, and other safety devices adjacent to and on the tract site as
may be necessary to prevent accidents to the public and damage to the property.
DEVELOPER shall furnish, place, and maintain such lights as may be necessary for
illuminating the said fences, barriers, signs, and other safety devices. At the end of all work
to be performed under this Agreement, all fences, barriers, regulatory signs, warning iights,
and other safety devices (except such safety items as may be shown on the plans and
incfuded in the items of work) shal! be removed from site of the work by the DEVELOPER,
and the entire site left clean and orderly.
10. Acceptance of Work.
Upon notice of the completion of all tract work and the delivery of a set of final as-built
plans to CITY by DEVELOPER, CITY, through its City Engineer or his designated
representative, shall examine the tract work without delay, and, if found to be in accordance
with said plans and specifications and this Agreement, shall recommend acceptance of the
work to the City Councii and, upon such acceptance, shalf notify DEVELOPER or his
designated agents of such acceptance.
11. Patent and Copvriqht Costs.
In the event that said plans and specifications require the use of any material, process
or publication which is subject to a duly registered patent or copyright, DEVELOPER shall be
liable for, and shall indemnify CITY from any fees, costs or litigation expenses, including
attorneys' fees and court costs, which may result from the use of said patented or copyrighted
material, process or publication.
12. Alterations in Plans and Specifications.
Any alteration or alterations made in the plans and specifications which are a part of
this Agreement or any provision of this Agreement shafl not operate to release any surety or
sureties from liability on any bond or bonds attached hereto and made a part hereof, and
consent to make such alterations is hereby given, and the sureties to said bonds hereby
waive the provisions of Section 2819 of the Civil Code of the State of California.
13, Liabifitv,
A. DEVELOPER Primarily Liable. DEVELOPER hereby warrants that the
design and construction of The Improvements will not adversely affect any portion of
adjacent properties and that all work will be performed in a proper manner.
DEVELOPER agrees to indemnify, defend, release, and save harmless CITY, and
each of its elective and appointive boards, commissions, officers agents and
employees, from and against any and all loss, claims, suits, iiabilities, actions,
damages, or causes of action of every kind, nature and description, directly or
indirectly arising from an act or omission of DEVELOPER, its employees, agents, or
1 S~ a,~
independent contractors in connection with DEVELOPER'S actions and obligations
hereunder; provided as follows:
1) That CITY does not, and shall not, waive any rights against
DEVELOPER which it may have by reason of the aforesaid hold harmless
agreement, because of the acceptance by CITY, or the deposit with CITY by
DEVELOPER, of any of the insurance policies described in Paragraph 4 hereof.
2) That the aforesaid hold harmless agreement by DEVELOPER shall
apply to all damages and claims for damages of every kind suffered, or alleged
to have been suffered, by reason of any of the aforesaid operations referred to
in this paragraph, regardless of whether or not CITY has prepared, supplied
[STAYS], or approved of plans and/or specifications for the subdivision, or
regardless of whether or not such insurance policies shall have been
determined to be applicabie to any of such damages or claims for damages.
3) Desiqn Defect. If, in the opinion of the CITY, a design defect in the
work of improvement becomes apparent during the course of construction, or
within one (1) year following acceptance by the CtTY of the improvements, and
said design defect, in the opinion of the CITY, may substantially impair the
public health and safety, DEVELOPER shall, upon order by the CITY, correct
said design defect at his sole cost and expense, and the sureties under the
Faithful Performance and Labor and Materials Bonds shall be liable to the CITY
for the corrective work required. [STAYS]
4) Litiqation Expenses. In the event that fegal action is instituted by
either party to this Agreement, and said action seeks damages for breach of
this Agreement or seeks to specifically enforce the terms of this Agreement,
and, in the event judgment is entered in said action, the prevailing party shall be
entitled to recover its attorneys' fees and court costs. If CITY is the prevailing
party, CITY shall also be entitled to recover its attorney's fees and costs in any
action against DEVELOPER's surety on the bonds provided under paragraph 3.
14. Recitals.
The foregoing Recitals are true and correct and are made a part hereof.
IN WITNESS WHEREOF, the parties hereto have executed this Agreement in
duplicate at Dublin, California, the day and year first above written.
CITY OF DUBLIN
BY:
Joni Patti(lo, City Manager
9
~~~>~~~
~
ATTEST:
City Clerk
DEVELOPER
K. Hovnanian at Positano LLC
A California Limited Liability Company
By: ~ ~2 ~l~
SENIOR~V.P., lAND
Title
G:IDEVELOPMENT, PRIVATE1Fallon Village (EDPO)ITract 8036 - Braddock & IoganlTract 8036 improvement agmtdoc
10
t1iACKAY & SOmPS
ENGINEERS PLANNERS SURVEYORS
BOND ESTIMATE
FALLON VILLAGE - NEIGHBORHOOD C1 - 78 LOTS
This Bond Estimate is based on Improvement Plans dated April 2010
TRACT 7855 - CITY OF DUBLIN
ITEM QUANTITY UNIT DESCRIPTION
UNIT PRICE
AMOUNT
A. STREE111VORK
1• 210,580 SF Finish grading street
2• 25,100 SF 4" AC Pavement on Salerno 0.30 $63,170
3~ 102,780 SF 3" AC pavement on all other streets 1.60 40,160
4• 25,100 SF 14" AB on Saferno 1.20 123,340
5. 102,780 SF 12" AB on all other streets 2•10 52,710
6~ 43,810 SF 4" AB under sidewalk and drivewa includes
Y~ ~'B~ 185,000
handicap ramps) 0.60 26,290
~~ 10,830 SF 4" AB under curb & gutter
$~ 25 EA Standard City of Dublin street monument 0.60 6,500
9~ 5 EA Stop and street name sign 300.00 7,500
10. 5 EA Stop bar & legend 450.00 2,250
11. 5 EA Traffic signs 600.00 3,000
~2• 10 EA Pavement reflectors at fire hydrants 22~•00 1,100
13. 15 EA Storm drain markers at catch basins 25.00 250
14. LUMP SUM Erosion Control 25.00 380
15. LUMP SUM Traffic striping 4,500
ESTIMATED TOTAL STREET WORK: 2,000
$518,150
B. CONCRETE WORK
~•
2 7,220
15 LF Standard curb & gutter measured thru driveways 14.00
~101
080
~ EA Curb inlet for S.D. junction box ,
3~ 31,330 SF 4" Sidewalk & handicap ramps 2,500.00 37,500
4~ 12,480 SF 6" Driveway approach 3•20 100,260
5~ 156 EA 3" PVC thru curb drains 3,50 43,680
6• 11 EA Armor-tile domes in handicap ramps 50.00 7,800
~~ 7,220 LF 4" SDR drain under curb & gutter 400.00 4,400
ESTIMATED TOTAL CONCRETE WORK: 8.00 57,760
$352,480
~
~~ 1 ~~~
~
19319.01 C
6/16/2010
J.R.F.
~sa~a-o~cpr zo~o-o~.»_N-ci_T~~ass.eoNa~e~omxm Page 1 of 3 ~'~'~ /~
~r~
r~~
To the Agreement
macKaY & somps
ENGINEERS PLANNERS SURVEYORS
ITEM QUANTITY UNIT DESCRIPTION
UNIT PRICE AMOUNT
C. STORM DRAIN WORK
~• 1 EA Manholes including reset to finish grade
2~
1,311
LF
24" Storm drain 2 900.00
~
~2,g00
3~ 2,156 LF 18" Storm drain 50.00 65,550
4• 281 LF 15" Storm drain 40.00 86,240
5~ 808 LF Scour protection 36.00 10,120
1.25 1,010
ESTIMATED TOTAL STORM DRAIN WORK:
$165,820
D. ELECTRICAUJOINT TRENCH
~~ 24 EA Single arm "Decorative" electrolier including 3,500.00
conduit & boxes $84,000
2~ 3,610 LF Joint trench (length of improvements
) 60.00 $216,600
ESTIMATED TOTAL ELECTRICAL WORK: $300,600
E. MISCELLANEOUS CONSTRUCTION
180 LF 6" Irrigation sleeves 18.00
$3,240
ESTIMATED TOTAL MISC. CONSTRUCTION: $3,240
F. LANDSCAPE 8~ IRRIGATION
~• 26,930 SF Parkway strip landscaping
2• 85 EA Street trees in-tract 4.00 $107,720
3• 8,080 SF 10' Parcel landscaping each side La Strada 250.00 21,250
ESTIMATED TOTAL LANDSCAPE PLANTING 8
IRRIGATI 2.50 20,200
,
ON: $149,170
SUMMARY
A STREETWORK $518
150
B CONCRETE WORK ,
C STORM DRAIN WORK 352,480
~ ELECTRICAL/JOINT TRENCH 165,820
E MISCELLANEOUS CONSTRUCTION 300,600
F LANDSCAPE & IRRIGATION 3,240
149,170
ESTIMATED IMPROVEMENT COST:
$1,489,460
CONTINGENCY 10% $148,950
TOTAL BOND ESTIMATE: $1,638,410
/g~~ ~~
19319.01 C
s/~ 6/2~ ~ 0
J.R.F.
19719-01Cjr1_2070-01-11_N-01-Tr785SBON0.78Lotsxk Page 2 of 3
r)
~ ~~,~
~
macKaY ~ somps
ENGINEERS pLANNERS SURVEYORS
NOTES
This estimate is prepared as a guide only and is subject to possible change. It has been prepared
to a standard of accuracy which, to the best of our knowledge and judgment, is su~cient to satisfy
our understanding of the purposes of this estimate. MacKay & Somps makes no warranty, either
expressed or implied, as to the accuracy of this estimate.
This estimate does not consider the following:
a. Land costs, acquisition of Right of Way, easements, and/or rights of entry.
b. Fees for assessment, lighting & landscaping, GHAD, Mello Roos districts or the like.
c. Fencing
d. Costs associated with trench shoring.
e. City fees.
f. Phased construction or out of regular sequence construction.
g. Tree preservation systems.
h. Landscaping & associated design costs
I. Financing and overhead charges.
j. Costs associated with Endangered Species and Wildlife Conservation.
k. Cost associated with Corps of Engineers, Fish and Game, Fish and Wildlife and Wetlands
I. Costs associated with overexcavation of unsuitable material.
3. Costs presented herein represent an opinion based on historical information. No provision has
been made for inflation.
4. As noted above this estimate does not include costs associated with right-of-way acquisition or
temporary grading/construction easements.
Prepared by the firm of
MACKAY & SOMPS
19319.01C
6/16/2010
J.R.F.
1931301C~A 2070-01-11 N-C1-Tr7855$OND-79LOtsxls Page 3 of 3
~~~ ~
~
/
,
.
,
-~-
o~ ~aa~ 4U0' 804~
sca~~: ~°=~oa~
LeQend:
0 Tract 8036 Pinal ~1ap
{691ats)
~ Neigh. Ci Impror~ements
and F3ondrng
,~ Tract 8U37 Final Map
{68 tot~}
~ Nei~h. C2 ImproV~ements
and B~ncling
~ 7ract 7~55 Finsl Map
{First Map for Nei~h. C3)
Z~i G~ lats, 6 bulk parcels)
~ :'~teigh. C3 Improvements
R11CI Bi7Ct{I1IIf~T
~ La Strada Dr, Improvements
and Bonding
~[BIT
~
~he Agreement