HomeMy WebLinkAbout8.1 Att 3 PC Reso Recom CC approval DA Extension RESOLUTION NO. 14-xx
A RESOLUTION OF THE PLANNING COMMISSION
OF THE CITY OF DUBLIN
RECOMMENDING THAT THE CITY COUNCIL ADOPT AN ORDINANCE APPROVING AN
AMENDMENT TO THE DEVELOPMENT AGREEMENT BETWEEN THE CITY OF DUBLIN
AND PROLOGIS, INC. TO ALLOW FOR AN EIGHTEEN MONTH TIME EXTENSION WITH
CONDITIONS
PLPA-2014-00006
WHEREAS, Prologis, Inc., has submitted a request for a time extension to the existing
Development Agreement ("Amendment No. 1 to Development Agreement between the City of
Dublin and Prologis, Inc. (formerly known as AMB Property Corporation") for the project known
as the West Dublin Transit Village), which is located at 6700 Golden Gate Drive (APN 941-
1500-04-04); and
WHEREAS, the existing Development Agreement vested the Site Development Review
and Tentative Map approvals that were granted in 2004 for a ten year period and will expire on
June 3, 2014 unless extended before that time; and
WHEREAS, the Developer requested an extension and City Staff supports three
consecutive six month extensions (eighteen months total) assuming that certain conditions can
be met; and
WHEREAS, on April 20, 2004, the City Council adopted Resolution 67-04, adopting a
Mitigated Negative Declaration (MND) and Mitigation Monitoring Program for the AMB
Properties Transit Village Project (PA 02-003). Approval of the Development Agreement was
an action covered by the MND and therefore an extension to the time period that the
Development Agreement is effective does not require additional environmental review; and
WHEREAS, the proposed Development Agreement Amendment is attached to this
Resolution as Exhibit A-1; and
WHEREAS, on March 25, 2014, the Planning Commission held a public hearing on the
proposed Development Agreement Amendment; and
WHEREAS, proper notice of the public hearing was given in all respects as required by
law; and
WHEREAS, the Staff Report was submitted recommending that the Planning
Commission recommend that the City Council adopt an Ordinance approving the Development
Agreement Amendment; and
WHEREAS, the Planning Commission did hear and use their independent judgment and
considered all reports, recommendations, and testimony hereinabove set forth.
NOW, THEREFORE, BE IT RESOLVED THAT the City of Dublin Planning Commission
does hereby recommend that the City Council make the following findings and determinations
regarding the proposed Development Agreement:
ATTACHMENT 3
1. The proposed Development Agreement Amendment is consistent with the
objectives, policies, general land uses and programs specified in the General Plan and
Downtown Dublin Specific Plan in that: a) the General Plan and Downtown Dublin Specific Plan
land use designation for the subject site is Downtown Dublin — Transit Oriented District and is
consistent with those designations; and b) the project is consistent with the fiscal policies in
relation to provision of infrastructure and public services of the City's Downtown Dublin Specific
Plan/General Plan.
2. The proposed Development Agreement Amendment is compatible with the uses
authorized in, and the regulations prescribed for, the land use districts in which the real property
is located.
3. The proposed Development Agreement Amendment is in conformity with public
convenience, general welfare, and good land use practice in that the Applicant's proposed
project will implement land use guidelines that were in place at the time the project was
approved.
4. The proposed Development Agreement Amendment will not be detrimental to the
health, safety, and general welfare in that the development will proceed in accordance with the
General Plan, Downtown Dublin Specific Plan, Project Approvals, and any Conditions of
Approval for the proposed project.
5. The proposed Development Agreement Amendment will not adversely affect the
orderly development of the property or the preservation of property values in that the
development will be consistent with the City of Dublin General Plan, Downtown Dublin Specific
Plan, and future Project Approvals.
NOW, THEREFORE, BE IT FURTHER RESOLVED THAT the City of Dublin Planning
Commission does hereby recommend that the City Council adopt the Ordinance, included as
Exhibit A, approving an amendment to the Development Agreement between the City of Dublin
and Prologis, Inc. to allow for an eighteen month time extension with conditions.
PASSED, APPROVED AND ADOPTED this 25th day of March 2014.
AYES:
NOES:
ABSENT:
ABSTAIN:
Planning Commission Chairperson
ATTEST:
Assistant Community Development Director
G:IPA#120141PLPA-2014-00006 ProLogis DA extension103.25.14 PC hearing1Att 3-PC Reso DA.docx