Loading...
HomeMy WebLinkAbout4.6 Approve Final Map Tract 5780 CITY OF DUBLIN AGENDA STATEMENT City Council Meeting Date: January 11, 1988 SUBJECT: Approval of Final Map, Tract 5780 Village VII - "Woodlands" (Standard-Pacific) EXHIBITS ATTACHED: 1) Resolution: Acceptance of Final Map 2) Reduced Copy of Final Map Tract- Developer Contract Contract 4) Performance Bond and Labor and Materials Bond 5) Location Map RECOMMENDATION. Adopt Resolution Accepting Final Map, Tract 5780. FINANCIAL STATEMENT: None at this time. Staff's time for processing and inspection is being paid for by the developers. DESCRIPTION: The Master Tract Final Map and Improvement Plans for the Villages at Alamo Creek (Tract 5511) were approved by the City Council in September of 1986. Tract 5780, Village VII "Woodlands," is a 139-apartment/condominium development located along the south side of the terminus of Shady Creek Road and is being developed by Standard Pacific-Northern California. The Tentative Map for Village VII was conditionally approved by the Planning Commission on May 18, 1987. Staff has reviewed the Final Map and Improvement Plans for Village VII and found them to be in accordance with the Tentative Map. The developer has submitted the proper bonds and insurance certification. This project is slightly different from the other high density Villages in that the units are being developed as townhouses rather than stacked units. The condominium Final Map is platted by separating each building (group of attached units) and will further be divided by airspace condominiums. The other developments in the Villages are subdivided as single large lots, each covering one Village, and then further divided as airspace condominiums. "Parcel A" as noted in the Resolution is being dedicated to the City as open space to become part of the existing Dougherty Hills open space. Staff recommends that the City Council adopt the Resolution Approving the Final Map for Tract 5780. ITEM NO. COPIES TO: Rafanelli & Nahas Standard Pacific RESOLUTION NO. -88 A RESOLUTION OF THE CITY COUNCIL" OF THE CITY OF DUBLIN • ACCEPTANCE OF FINAL MAP TRACT NO. 5780 WHEREAS, the Final Map of Tract No. 5780 in the incorporated territory of the City of Dublin, State of California, has been presented to this City Council for approval, all in accordance with the provisions of the Subdivision Map Act of the State of California and the Ordinance Code of the Wiz. ,; C:ounty. oftrAlanl ca,.gas-adap tech:=:az d._amende_d.--by-::the CityFof.-Dublin;•=and= WHEREAS, the Developer,. Standard Pacific-Northern California has ' executed and filed with the City of Dublin contracts to improve Tract No. 5780 in accordance with the Final Map of said Tract No. 5780, the Tract Improvement Plans and the specifications attached thereto; and ' . WHEREAS, said Contract is secured by a bond in the amount of $390,797 which, by its terms, is made to inure to the City of Dublin conditioned upon the performance of said contracts; and WHEREAS,' said Contract is secured by a bond in the amount of $195,398.50 which, by its terms, is made to inure to the benefit of laborers and materialmen upon such work and improvements, conditioned upon- the payment ' of such laborers and materialmen for labor performed or material furnished under the terms of said contracts. NOW, . THEREFORE, BE IT RESOLVED that said contracts and bonds be and they are hereby approved; , BE IT FURTHER RESOLVED'that. the Final Map of Tract No. 5780 be and the same is hereby approved; and that the parcel of land designated as "Parcel A" as offered for "dedication to public use in conformity with the terms of dedication be, and it is hereby accepted; and that those strips of land designated as "P.S.E. " "or "Public Service Easement" and "E.V.A.E. " or "Emergency Vehicle Access Easement" as offered for dedication to public use in conformity with the terms of dedication be, and they are hereby rejected; and that the Clerk of this City Council be and is hereby directed to transmit said Map to the County Recorder for filing. PASSED, APPROVED, AND ADOPTED this 11th day of January, 1988. AYES: NOES: ABSENT: ' Mayor ATTEST: City Clerk s; c C-- , t 41\ rJ %P , 1 • i 1, s(4.cif! -, cn (-, ,( ! fs No.4:(414.'s .k C f- �4`n y '604 h CoCS :1 ,� \.. s 0-,....,4 14 Mil r M,v to••• �3(4/ Li-) •b: d\ Y6 15 4� 19 I O PARCEL.F �. 0 . i \ SHEET w Q r— — v.am.__` •. /1� • L P 16 8/ \.I v Li� i ►"is: P/.FC L O t'. ►� • sc.! _ _ PARCEL p �� �� v Al Cr) u`1t1 J PARCEL C ospga` N.40 �` I t. I t 1 • u o r.ras� ..�r R ar O ('; f JI� .i of 3 a 6 op I E 5 , \►� r l .,v . 0 Z�` ` V 6 5 L 7 PARCEL F . Jv`� .r '1'^- •I ` o ``oee © i ..1•p.'CTV 1►.L. M0.p.. `J J� ` l }r w.= RCEI.. 5•195E `'., -l" '�, O PP. ' to51115 co.FL.p55 p?�.. .�,.' l` / . " L A SEMi0 VA 1p1p15•• ��0•4". moo•` 6 •lit' 44' 5.0'EA°` �?10 v0,T O��p15°3 17�'ns Ys; j1 � i•Ve•-u w . : - QA�.E1.0 a s . ....dd.. ••tog"'" 6EP 1 Vp�i,�'pa+/j. lea O ``'tea • ,•., NG. 6� 0D 1 A.C.r C, L:. W.C,D. FAC=E ,C• NWN'MY. :th�►S a.m:e ^ N•► t5 51 YE1T k SERIES ES N D. c -07693 • r .r��l� ! its EAtaE E r r I crr ��).� �rrl„���� ".111::°":----,4,.: } i , . rs r ;' RE Ell/ ED mACKaY&comps JAN Iti, PURUC WORKS CITY OF DUBLIN TRACT DEVELOPER AGREEMENT This agreement is made and entered into this day. of , 198_, by and between the City of Dublin, a municipal corporation, hereinafter referred to as "CITY", • and.Pulte Homes Corporation, hereinafter referred to as "DEVELOPER". . W I T N E S S E T H WHEREAS, it has been determined by the City Council of-the City of Dublin,. State of California, that DEVELOPER, as a subdivider, desires to improve and dedicate Tract 5780 in accordance with the requirements and conditions set forth within the City of Dublin City Council Resolution No. 32-86 adopted March 24, 1986, and Planning Commission Resolution No. 87-034 adopted on May 18, 1987; the requirements of the Subdivision Map Act of the State of California and the Subdivision Ordinance of the City of Dublin; and those certain plans and specifications for said development approved by said City Council, and definite and distinct description of. the work to be performed under this Agreement as though set forth at length herein; and WHEREAS, Developer intends to satisfactorily complete the required improvement within the time hereinafter specified, and City intends to accept Developer's offer(s) of dedication of said improvement(s) in consideration for Developer's satisfactory performance of the terms and conditions of this Agreement: NOW, "THEREFORE, in consideration of the mutual promises, conditions and covenants herein contained, the parties agree as follows: 1.. Completion Time. Developer will commence the work required by this Agreement within thirty (30) days following the date on which City executes this Agreement. Developer shall complete said work not later than three hundred sixty-five (365) days following said date of execution. Time is, of the essence. in this Agreement. Upon completion, Developer shall furnish City with a complete and reproducible set of final as-built plans, including any authorized modifications. - 2. Bonds Furnished. Concurrently with the execution of this Agreement, Developer shall furnish City with a Faithful Performance Bond and 'a Labor and Materials Bond. Each bond shall be in a form prescribed by City., and shall be issued by a company duly and legally licensed to conduct a general surety business in the State of California. Each bond shall become a part of this Agreement. a. Faithful Performance Bond. Developer shall furnish .City with a bond conditioned upon the faithful performance of this Agreement, said bond to be in the penal sum of $390,797.00. • b. Labor and Materials Bond. Developer shall furnish.City with a bond conditioned upon payment of all claims for labor and materials used or consumed in the performance of this Agreement. Said bond- shall comply with the laws of the State of California, and with Title 15, Part 4, Division 3 of the Civil Code of the State of California (commencing with Section Said bond shall be in the penal sum of $195,398.50. 3. Insurance Required. Concurrently with the execution of this Agreement, Developer shall furnish City with evidence of insurance coverage as specified below. a. Worker's Compensation Insurance. .Statutory coverage as required to cover the full liability of Developer in accordance with the provisions of. Division IV of the Labor Code of the. State of California,' and an employer's liability insurance coverage with a limit of not less than $100,000 per occurrence to cover any claims arising from employment not covered by worker's compensation laws. b. Comprehensive General Liability Insurance. Minimum limits of liability shall not be less than $1,000,000 per occurrence combined single limit bodily injury and property damage coverage; any deductible provision shall not exceed $1,000 per claim, and each and every policy must contain a cross liability or severability of - interests clause. c. Comprehensive Automobile Liability Insurance. Minimum limits of liability shall be not less than $1,000,000 per. occurrence combined single limit bodily injury and property damage coverage; coverage shall include owned, non-owned, and hired vehicles, and each and every policy must contain a cross liability of severability of interests clause. d. Otl Requirements. All insurance l Lcies 'shall be issued by a company legally licensed to transact business in the State of' California,- shall be issued at Developer's own cost and expense, shall be maintained by Developer .in full force and effect during the life of this contract, 'and must .have an "A.M. BEST" rating of B+, X or . better. All certificates of insurance shall name the City and its .officers, agents and employees as additional insureds, shall contain a provision that a written notice of cancellation or reduction in coverage shall'be furnished the City (10) ten days in advance of the effective date thereof, and shall state that such coverage is primary to any other ' - coverage of City. 4. Work Performance and Guarantee. Developer shall secure the services of those skilled in the trade, profession, or calling°necessary to perform the work to be : - accomplished under the terms of this contract, and shall guarantee and maintain the work for a period of one (1) year following the completion and acceptance thereof against any defective workmanship or defective materials furnished in the performance of this Agreement, and shall guarantee and maintain .the work for a period of one (1) year - following the completion and acceptance thereof against any defective workmanship or • defective amaterials.furnished -in_:the_.performance.of._ahs:contract,- and ;any.- acceptance-of =tl e avork° jy�City-will` riot°operate° as°a''rele'ase to'�D"eveloper"-6i1Y64'7operi"s IS`ondsmen'"£romJ""" ' the aforesaid guarantee. • 5. Inspection of the Work. Developer shall guarantee free access to City through its City Engineer- and his designated representative for the safe and convenience inspection of the work throughout its construction. Said City representative shall have the authority to reject all materials and workmanship which are not in accordance with the • plans and specifications, and all such materials and/or work shall be removed promptly by Developer and replaced to the satisfaction of City without any expense to City in strict accordance with the improvement plans and specifications. .' 6. -Agreement Assignment. . This Agreement shall -not be-assigned by Developer .without the written consent of City. 7. Abandonment -of Work. If the work to be done under this Agreement is abandoned, or if this Agreement is assigned by Developer without written consent of City, or if City through its City Engineer determines .that the said work or any part thereof is being unnecessarily or unreasonably delayed or that Developer is willfully violating any - of the conditions or covenants of this Agreement or is executing this Agreement in bad faith, the City shall have the authority to order Developer to discontinue all work or any part thereof under this Agreement, and Developer shall cease to continue the work or such . part thereof as City may designate, and .CITY shall thereupon.have the power to obtain by Agreement, purchase, rental or otherwise, all labor, equipment, and materials .deemed necessary'to 'complete the work and to use such materials as maybe found upon the line of such work. Developer and his sureties shall be liable for all expenses incurred by"City for the acquisition and use of such labor, equipment, and'materials. 8. Use of Streets or Improvements. At all, times prior to the final acceptance of the work by City, the use of any or all streets and improvements within .the work to be performed under this Agreement shall"be at the sole and exclusive risk of Developer. The issuance of any building or occupancy permit by City for dwellings. located within the tract shall not be construed in any manner to constitute a partial or final acceptance or approval of any or all such improvements by City. Developer agrees that City's Building Official may withhold the issuance of building or occupancy _permits when the work or its progress may substantially and/or,detrimentally affect public health and safety. • 9. Safety Devices. Developer shall provide and-maintain such guards, watchmen, fences, barriers, regulatory signs, warning lights, , and other safety devices adjacent to and on the tract site as may be necessary to prevent accidents to the public and damage to the property. Developer shall furnish, place, and maintain such lights as may be necessary for illuminating the said fences, barriers, signs,' and other safety devices. At the end of all work -to be performed under this Agreement; all fences, barriers, regulatory signs, warning lights, and other safety devices (except such safety items• as may be shown on the plans and included in the items of work) shall .be removed from site of the work, by the Developer, and the entire site left clean and orderly. . 10. Acceptance of Work. Upon notice of the completion of all tract work and the delivery of a set of final as-built plans to City by Developers, City, through its . City Engineer, or his designated representative', shall examine the tract work without delay, and, if found to be in accordance with said plans and specifications and this Agreement, shall accept the work and notify Developer or his designated agents of,such acceptance. • 11. Patent and Copyright Costs-.' In the event that said plans and specifications require the' use of,any material, process or publication which 'is subject to a duly registered patent or copyright, Developer shall be\liable for, and shall • • indemnify City from, an' :es, costs or litigation.expen: .including attorneys' fees and court costs, which may result from the use of said patented or .copyrighted.material, process of publication. 12. Alterations in Plans and Specifications. Any alteration or alterations made in the plans and specifications which are a part of this Agreement or any provision of this Agreement shall not operate to release any surety or sureties from liability on any bond or bonds attached hereto and made a part hereof, and consent to make such alterations is hereby given, and the sureties to said bonds hereby waive the provisions of Section 2819 of the Civil Code of the State of California. 13. Liability: a. Developer Primarily Liable. :Developer shall be responsible for any and all loss, accident, neglect, injury or damage to person, life or property which may be the result of or may be caused by construction, operations, or execution of this Agreement„,and_Tfo,r which_City might be held, .liable Developer shall .protect and indemnify ._ '--:--the--City °of-Dublin; the 'Ci'ty °Council,-'the°'City Engineer aria/or'any employee of the City, and save them harmless in every way from all suits or actions at law for damage or injury to persons, life or property that may arise or be occasioned in any way because of construction operations or execution of this Agreement. b. 'Design Defect. If, in the opinion of the City, a design defect in the work of improvement becomes apparent during the course of construction, or within one (1) year following acceptance by the City of the improvements, and said design defect, in the opinion of the City, may substantially impair the public health and safety, Developer shall,, upon order by the City, correct said design defect at his sole cost and expense, and the sureties under the Faithful Performance and Labor and Materials Bonds shall be liable to the City for the corrective work required. c. Litigation Expenses. In the event that legal action is instituted by either party to this Agreement, and said action seeks damages for breach of this Agreement or seeks to specifically enforce the terms of this Agreement, and, in the event judgment is entered in said action, the prevailing party shall be,entitled_ to recover its attorneys' fees and court costs. - IN WITNESS WHEREOF, the parties hereto have executed this Agreement in duplicate at Dublin, California, the day and year first above written. , ' CITY OF DUBLIN By Mayor ATTEST: City Clerk DEVELOPER ' A/-.1 By - �t. IIPEMAN•i S INIUA•NCL COM P■NY -; . - j - . 7131916 r THE AMiNI riiumANet COMPANY Bond lic. � �� `NATIONAL .U11t,Y COM.ORATIOH FEMANS run 1.0‘..,,,,,,c...0AA110N . _ Premium: 52,345.00 TR iINSURANCE COMPANIES AMtAICAM AUTOrdPILt INSUAANCt COM►ANT . RECEIVE ; • •- S E P ::;.0 ' SUBDIVISION IMPROVEMENT BOND • STANDARD PACIFIC FAITHFUL -PERFORMANCE (CALIFORNIA) - , • ' . Whereas, , CITY OF DUBLIN , ' . . • State of California, and STANDARD PACIFIC, L.P.P (hereinafter designated as ."principal") have entered , into an agreement whereby principal agrees to install and complete certain ' designated public improvements, which said agreement, dated , 19 , and identified as project - TRACT #5780 .. • . is hereby referred to and made a part hereof; and Whereas, Said principal is required under the- terms of said agreement to furnish ' `; a bond for the faithful performance of.said agreement. .� Now,. therefore, we, the principal and THE AMERICAN INSURANCE COMPANY as surety, are held and firmly bound unto the CITY OF DUBLIN _ i • hereinafter called "Obligee", n the penal sum- of ' THREE HUNDRED NINETY THOUSAND SEVEN HUNDRED NINETY SEVEN AND NO/100ths . dollars' ($ 390,797.00 .) lawful money. of the United States, for the payment of • which sum well and truly to be made, we bind ourselves, our heirs, successors, executors and administrators,' jointly and severally, firmly by there presents. . The condition of this obligation is such that if the above bounded principal , his or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by', and well and truly keep and perform the covenants , conditions and provisions in the said agreement and any alteration thereof made .as therein provided, on his or their part, to be kept and performed at the time and in' the manner therein specified, and in all respects according to their true intent and meanina,' and shall indemnify and save harmless the Obligee, its officers, agents • and employees, as therein stipulated, then this- obligation shall become null and void; otherwise it shall be and remain- in full force and effect. • As a part -of the obligation secured hereby and in' addition to the face amount specified therefore, there shall be included costs and reasonable expenses and fees, including reasonable attorney's ' fees, incurred by the Obligee in successfully enforcing such obligation, all to be taxed as .costs and included in any judgement rendered. . The .surety hereby stipulates and agrees that no change, extension of time, • alteration or addition to the terms of the agreement or to the work to be performed thereunder or the specifications accompanying the same shall in anywise' affect its. . . obligations on this bond, and _it does hereby waive notice of any such change, extension of time; alteration or addition to the terms of the agreement of to the work or to the .specifications. In witness whereof.- this instrument hat been duly executed by the principal and surety -above named. on September 23, ' , 19 87 , • STANDARD PACIFIC, L.P. THE AMERICAN INSURANCE COMPANY •Principal ,' Surety :. • A _. o /.r B )\44. �__&. N `y . Tho -s G. McCall . ttorney-In- act . • / , . , .7., ., Address• nos...',,,,......,,,.f'Fa ,..T..).1' -.r.r44.4..,4,4n3ei+......i:r:tw..u41,43,.++-W4:/ww.•.>_..',L.N.vw.4V:.a...ua t,.:..,„,,.......7-......u+:xu.:.,..........us...4.7,M."Z!1,v......, '2:ainr,• J STATE OF CALIFORNIA )SS. c COUNTY OF On JCL a�, /9,7 /� before me,the,undersigned,a Notary Public in and for said State, ers pally appeared i • /t �-�/ and w p ersonally known to me(or proved to on the ' basis of satisfactory evidence)to be the persons who executed the within Instrument as Authorized Representatives)on behalf of Stan Pac Corp.,a Delaware Corporation,the corporation therein named,and acknowledged to me that said corporation executed the within instrument pursuant to its bylaws • . •- or a resolution of Its board of directors,said corporation being known to me to be the general partner of Standard Pacific,LP,a rti�-� a�-∎��_`�'_,�_�-�_��-�l_-`�-`,N) Delaware Umited Partnership,the limited partnership that executed r - OFFICIAL SEAL . ”_ f the within Instrument,and acknowledged to me that such corpora- I /?' ' '11,' KATHY MARSH tion executed the same as such partner and that such partnership i .ate •-' - mg r' „-CR.M.1.A executed the same. I • I� MESA CO - ,,:i My COMM.Wires Jan.5,1988 WITNESS my hand and official seal. I � . I. � Signature A A'Ldi I/I _/ (This area for official notarial seal) ATTORNEY IN FACT ACKNOWLEDGMENT ,. STATE OF CALIFORNIA - County of—ORANGE i ss- _ . Oo this 23rd day of September ORANGE .in the year 1987 .before me.a Notary Public i ie and for said _County.State of California.residing therein.duly commissioned and sworn.personally fired Thomas G. McCall to be the $Xpersoaally known to me,Q proved to me on the basis of satisfactory eriderJCe Person whose name is subscribed to this instrument as the attorney in fact of TNF AMFRT('pT�r T*�G„rca t &!f f1MPaW and acknowledged CO me that Let he 0 she subscribed the name of THE suety, and his AMER1VruV LNSURAN ❑by own name as attorney in fact. — thereto as IN WITN WHEREOF. l have hereunto set my hand and affixed my official seal. the da • y and year stated in this certificate above. 's” `� OFFICIAL SEAL AA ,, �VICTORIA M CAMPBELL r �� po! i f ",`, ''"I.` Notary Public i ' = NOTARY PUBLIC CALIFORNIA t 4+y PRINCIPAL OANGE OFFICE IN r • \\`' GRANGE COUNTY My commission expires •70°`2—•••; `•'`�,,� ldy Commission Exp.Oct. 19, 1990 - _ • r , (�`}.► FIREMAN'S IYL URAHC[COMPANY Bond4No. 7131916 THE AMERICAN IANCE COMPANY -NATIONAL•URETY CORPORATION - ' fIREMANS FUND. ASSOCIATED INDEMNITY CORPORATION - The -Premium charged for this jMIE AMERICAN AUTOMOBILE INSURANCE COMPANY Bond is included in that shown on the Performance Bond SUBDIVISION IMPROVEMENT BOND LABOR AND MATERIAL (CALIFORNIA) Whereas, CITY OF DUBLIN • State of California, and STANDARD PACIFIC, L.P. (hereinafter designated as "Principal") have entered into an agreement whereby principal agrees to install and complete certain designated public improvements, which said agreement, dated 19 , and identified as project TRACT #5780 is hereby referred to and made a part hereof; and Whereas, Under the terms of said agreement, principal is required before entering upon the performance of the work, to file a good and sufficient payment bond with the . CITY OF DUBLIN to secure the claims to which reference is made in Title 15 (commencing with Section 3082) as Part 4 of Division 3 of the Civil Code of the State of California. • • Now, therefore, said principal and the undersigned as corporate surety, are held firmly bound unto ' CITY OF DUBLIN • (hereinafter designated as "Obl igee") and all contractors, subcontractors, laborers , • materialmen and 'other persons employed in the performance of the aforesaid agreement and referred to in the aforesaid Code of Civil Procedure in the sum of ONE HUNDRED NINETY FIVE THOUSAND THREE HUNDRED NINETY EIGHTY AND 5Q qqg rs ($ 195,39h. 0 )_I for materials furnished or labor thereon of any kind, or for amounts due under the Unemployment Insurance Act with respect to such work or labor, that said surety will pay the same in an amount not exceeding the amount hereinabove set forth, and also in case suit is brought upon this bond, will pay, in addition to the face amount thereof, costs and reasonable expenses and fees, including reasonable attorney's • fees, incurred by the Obligee in successfully enforcing such obligation, to be awarded and fixed by the court, and to be taxed as costs and to be included in the judgement therein rendered. • It is hereby expressly stipulated and agreed that this bond shall insure to the benefit of any and all persons, companies and corporations entitled to file claims under-Title 15 (commencing with Section 3082) of Part 4 of Division 3 of the Civil Code, so as to give a right of action to them or their assigns in any suit brought upon this bond. Should the condition of this bond be fully performed, then this obligation shall become null and void, otherwise it shall be and remain in full force and effect. The surety hereby stipulates and agrees that no change, extension of time, alteration- or addition to the terms of said agreement or the specifications accompanying the same shall in any manner affect its obligations on this bond, and it does hereby waive notice of any such change, extension, alteration or addition. • In witness whereof, this instrument has been duly executed by the principal and surety above named, on September 23, , 19 87 STANDARD PACIFIC, L.P. - THE AMERICAN INSURANCE COMPANY - Principal - Surety / Thomas G. McCall' Attorney-In-Fact 11119,41,74 i i 1I1!•" I ,"7" • / Address • � . 310702-10-1E iLaaA,L sl:t) - - . • • . } •STATE OF CALIFORNIA `o , h )SS. COUNTY OF CX,'// } • ' - cam/ / 9Y 7 - .,before me,.the undersigned,a.Notary.Publlc.Inand.for___._-_..,_ said State,personally appeared —191' a_- C a Oyyc.2/r. and ,personally known to me(or proved to me on the basis of satisfactory evidence)to be the persons who executed the within instrument as Authorized Representatives)on behalf of Stan Pac Corp.,a Delaware Corporation,the corporation therein named,and acknowledged to me that said corporation executed the within instrument pursuant to its bylaws or a resolution of its board of directors,said corporation being known to me to be the general partner of Standard Pacific,LP,a FA-5......---- t Delaware Limited Partnership,the limited partnership that executed ,:-.— ; OFFICIAL mow the within instrument,and acknowledged to me that such corpora- �� / ! I.:. $H • tion executed the same as such partner and that such partnership 'a •' t"TP��FtIBU°�CI If0`"r executed the same p p r;; ' `�.: f .7 ' �i_L:;F^P.GOU�fi f - WITNESS my hand and official seal. t_y --.-4-z,..-,:,-;_,.• �jl Cutom.Exw' Signature �� (This area for official notarial seal) ATI-ORNEY IN FACT ACKNOWLEDGMENT , • . STATE OF CALIFORNIA . r County of ORANGE ss• • Oa this 23rd •day of September ORANGE .m the year 198 .before me' e.a Notary Public in and for said _County.State of California.residing therein.duly commissioned and sworn,personally appeared Thomas G. McCall to be the lapersoaally known to me,Q proved to me on the basis of satisfactory evidence parson whose name is subscribed to this instrument as the attorney in fact of THE AMFR T('AN ThSTTR gT�T{'p'r nx e.,t and acknowledged to me that he 0 she subscribed the name of THE surstY, and his❑her awn name as attorney in fact_ — AMERICAN INSURAN E thereto as IN WITNESS WHEREOF. 1 have hereunto set my hand and affixed my official seal. the d year stated in this certificate •bove.li OFFICIAL SEAL A. A At klaili ' VICTORIA M. CAMPBELLL Notary Public °yam NOTARY PUBLIC CALIFORNIA I.,w PRINCIPAL OFFICE IN �S4y commission expires `1 0~�i/" ORANGE COUNTY �aoaa—�.•a �Y_ . . °,:.o..," My Commission Exp,Oct. 19, 1990 • • ., 4.: -- / 1 ( • . '-■`'")/// f/ '''-, *!.'(-,,-1-1,1 I rd r;; I • - I.. Z. .‘\.1, ,./Z.". ,.., ...... , ‘‘ —. • — -..., ..y, . ..... ‘‘ — .7 /, - .- -••., . . "./•••,. \ ., ' , 4. , -' t_ ... , .• . , , // / ( - ,,,)"', f) / s .1%, '17-1,1. -. _____....... \\......„.....- • // . - • .e• / . ." ; ,. ,,,,, .. • s , • .. , , I \• t--• -' ' '') . X 7/' ' /.....;'....-1 I .r... • ‘ //.;'•/. '' / ''', 4, ,, ''.. \ s ' . ....,;;Off-s .• , 1 . / .„...‘,,, //1!! .. . • r\ ( ,._ , .,, __, --•••• • - , ..... .„ z , i, ..,.. .,, ,,..;•... ,.. .„.„.. .s......,., . ... `,4•1= •'.. r' \, r'4.-•a \ li '.I , „ . /.■ ,• \ ,,,,i \,''k • '. \i'r'. i / I r ,,e ''' / / ' ,/ . • • \_,‘ \ /' , 4■P - ''.\----- a II. . 0 .,, ...,---•-"" ‘ ,"2...4,4;,' ,7-.., . \ „' ; . \ \ x ..- v. r Z.., ' ...' -- 1,. 1 t‘c 1 )<- . o ,1• \ .., ' / ...,/,,,......,,,.!,„..., , \(... -..,,, \_) ..„,,)" „.' ,,4;,--\,,:.\,,,, \ \—"J.\\ --•:,„. ...- ..-:, \\ ." -I. - -'\----. ' 1,.. / -.r.. s\>.o.' scAc- :'• — - .!‘ 1;s .... ..---- %,\• \ — • ir r r fi—r. 7 - - ' A - ?" -\c_ c ,•,.. ' \\ ? : ,- c,e' \/ 1 y'. ,,/ • :S..., , • \ / V . ...... (....._- \, 1— •. ,,,,: c - < ' 2( 1 ry,2-.. -- ? ..„.7• ,- ,;,,,.....-•\<-„--- - ,„(:,.----- .........‹ ., 1.,- , „, - ..-- •••• . / '• i 1 1 : /- _ ;,., . ,,,`., -- • ' . \s•;,---, •\.' '•.,, '"':-. 1 ' -- ,- ' - , - . ./.- .:1' / i . • - -- - .,.., ....:,•,.. - ...,,,,‘ ,.-- • \-- ,.. / -,., ;-. - ..-- . 77------ ' ,/ /,,- ,_ / if • . ,. . • . • - c .. • -,., - . , - , • ,... ..- .- .• .- ....;/ , •,„, -ry ,, v., . c. •. ' • ... ) .... ,... 1.; / , . 1 ,,. , ., 1,,,,„( .• ., , , i2 ....,,,, ,„ .. .... , -.• u, ,, , v, ,, .. . .6 • —Al.a.,,ii -• i.n.- .-, , ,) / /;-, ,;,• i . .,1 \.2',-;,)) 1 ,4"5 > .. ii r). • / i d , .4. . ' .•• \4,•••". '1.).4 ), ' • •,..../ / 4 i i . / \ '. ,\ , • " •- ,'- . . / !';'&..1-, _ri/ --• \ \ 0 • \ ,, I -------, 21 • . - .7 : \-- .4. -..... , \...."' e , • - ___,, . - ,..:\\\ • . \ . , ...7_ •,, , - . ' . • V 06 1 //•1 1.- ''' ..'' . • r....., • . --- ;.,.. 1 ' 14% A. .10 IIP ,. ,c-c lin '1 / . , 1 ..,.4 , _ T :al 3,Ir e.n iiiiimmo 4410 . „ . ...... _ .... / i. •/- „, . s / / . • • . 4,,, ,„,,,.. / • 7 ,./ i/ z ,/,--- / 1 „ 7 . , \ .. . _ -__ ) / • , . • ,; -. t t'4',0.' -..-..,,z 1 .,'•i,..' — - . („....__ . ___11 2 a . 1!1--11,— wo.'•'''' . 4.itt.',,•f.-: . ..-2- ,,0 -- ,., : :.,;,-..;::::-.,a-:g.. •-..,,Mea. ''' 4' '''- LI1,111 __. : . 170410,4•11, OD ...... , ,...• ••••• ■.,s 0.„,,,‘ . -- ..... ................ -,.- •••,..,..,..---;‘,„. , • . . ..t,,,,,t.iih',., • ---- . . , •'....).14114.,a-t. , . . -: ,,•. • I ', . ; 0d4 1'.. • Ci\ 0' , ' ib'4.1 .,,f ii .oll I t. .. '/. lfi I soI.Cloo . . • , rntAr i . \ ,,, /------- ..,„ ,,, '1 r, . • r I r i. ,.. r tr. s- ... En /ri• ! T-- .-. r. , I Pi r,