HomeMy WebLinkAbout4.05 Approve Amended Final Map Tract 4415 CITY OF DUBLIN S.0
AGENDA STATEMENT
City Council Meeting Date: September 22, 1986
SUBJECT: Approval of Amended Final Map, Tract 4415
EXHIBITS ATTACHED: Resolution: Acceptance of Amended Final Map
Tract Developer Contract
Performance Bond
Labor and Materials Bond
Reduced Copy of Final Map
Vicinity Map
RECOMMENDATION: Adopt Resolution Accepting Amended Final Map,
Tract 4415
FINANCIAL STATEMENT: The proposed streets within the project are to be
private and will be maintained by the Homeowners
Association following completion and acceptance of the
Tract by the City.
DESCRIPTION:
Improvement plans and the Amended Final Map for Tract 4415 have been
reviewed and found to be in conformance with the Tentative Map and conditions
approved by the County of Alameda on December 17, 1979, and corrected on
February 19, 1980, and as amended by the City of Dublin Planning .Commission
Site Development Review Conditions of Approval dated July 31, 1986.' This
tract consists of 26 residential multi-family townhouse lots.
The original Final Map was accepted by Alameda County in October of
1980, and bonds and parkland in-lieu fees were submitted to the County at that
time; however, the original subdivider did not complete the project. These
original bonds will now be released.
In March of 1986, Plummer and Babbitt requested, and were granted,
permission to replace the original engineering firm of William Black and
Associates as Engineer of Record for the Tract. They were required to file an -
Amended Final Map and will set the monuments for the subdivision.
A subdivision agreement, bonds, and fees have been submitted by Coral
Development Co. guaranteeing the construction of improvements within the
subject Tract.
---------------------------------------------------------------------------- -
ITEM NO. .► COPIES TO: Coral Development Co.
Plummer and Babbitt
.. s aa'>'' x F:'> .a R:L:,� .r� s�yf��s}pyK•'i'r:-i' t"•�v-lam i :„s'Ss& a. i _
RESOLUTION NO.... -86
A RESOLUTION OF THE CITY COUNCIL
OF THE CITY OF DUBLIN
ACCEPTANCE OF AMENDED FINAL MAP
TRACT NO. 4415
WHEREAS, the Amended Final Map of Tract No. 4415 in the
incorporated territory of the City of Dublin, State of California, has been
presented to this City Council for approval, all in accordance with the
provisions of the Subdivision Map Act of the State of California and the
Ordinance Code of the County of Alameda, as adopted by the City of Dublin; and
WHEREAS, the Developer, Coral Development Co. , has executed and
filed with the City of Dublin a contract to improve Tract No. 4415 in
accordance with the Amended Final Map of said Tract No. 4415, the Tract
Improvement Plans and the specifications attached thereto; and
WHEREAS, said Contract is secured by a bond in the amount of
$100,600, which, by its terms, is made to inure to the City of Dublin,
conditioned upon the performance of said contract; and
WHEREAS, said Contract is secured by a bond in the amount of
$50,300, which, by its terms, is made to inure to the benefit of laborers and
materialmen upon such work and improvements, conditioned upon the payment of
such laborers and materialmen for labor performed or material furnished under
the terms of said Contract.
NOW, THEREFORE, BE IT RESOLVED that said Contract and bonds be and
they are hereby approved;
BE IT FURTHER RESOLVED that the Amended Final Map of Tract No.
4415 be and the same is hereby approved; and that those strips of land
designated as "Calle de Casas" (A Private Street) , "P.U.E." or "Public Utility .
Easement," "P.A.E." or "Public Access Easement," and "A.E." or "Access
Easement," offered for dedication to public use in conformity with the terms
of dedication be, and they are hereby rejected; and that the Clerk of this
City Council be and is hereby directed to transmit said Map to the County
Recorder for filing.
BE IT FURTHER RESOLVED that the performance bond and labor and
materials bond of the original subdivider are hereby released.
PASSED, APPROVED, AND ADOPTED this 22nd day of September 1986.
AYES:
NOES:
ABSENT:
Mayor
T
ATTEST:
City Clerk
-i .....,,. '.r• nM1,�c";¢z ... ,^
RECEI VIE ®
CITY OF DUBLIN
AUG 111986
TRACT DEVELOPER AGREEMENT
PUBLIC WORKS
This ,agreement is made and entered into this _ day of August, 1986, by and
between the City 'of, Dublin, a municipal _corporat-ion,;. hereinafter referred to. as -.".CITY",
and Coral Development Corporation, hereinafter referred to as "DEVELOPER".
W I T N E S S E T H
WHEREAS,':._it has been determined by the City Council- of the City of Dublin,
State of California, that DEVELOPER, as a subdivider, desires to improve and dedicate
Tract 4415, % in accordance with the requirements and conditions set forth within the
Alameda County Planning Commission Conditions of Approval for Tract 4415 approved on
December 17, 1979; and corrected on February 19, 1980, and as amended by the City of
Dublin Planning Commission Site Development Review Conditions of Approval as approved by
Final Action Letter dated July 31, 1986, the requirements of the Subdivision Map Act of
the State of California and 'the Subdivision Ordinance of the City of Dublin; and those
certain plans and specifications for said development approved by said Planning
Commission, and now on file in the office of the City Engineer, which are hereby referred
to for a more definite and distinct description of the work to be performed under this
Agreement as though set forth at length herein; and
WHEREAS, Developer intends to satisfactorily complete the required improvement
within the time hereinafter specified, and City intends to accept Developer's offer(s) of
dedication of said improvement(s) in consideration for Developer's satisfactory
performance of the terms and conditions of this Agreement:
NOW, THEREFORE, in consideration of the mutual promises, conditions and
covenants herein contained, the parties agree as follows:
1. Completion ' Time. Developer will commence the work required by this
Agreement within thirty (30) days following the date on which City executes this
Agreement. Developer shall complete said work not later than three hundred sixty-five
(365) days following said date of execution. Time is of the essence in this Agreement.
Upon completion, Developer shall furnish City with a complete and reproducible set of
final as-built plans, including any authorized modifications.
2. Bonds Furnished. Concurrently with the execution of this Agreement,
Developer shall furnish City with a Faithful Performance Bond and a Labor and Materials
Bond. Each bond shall be in a form prescribed by City, and shall be issued 'by a company
duly and legally licensed to conduct a general surety business in the State of California.
Each bond shall become a part of this Agreement.
a. Faithful Performance Bond. Developer shall furnish City with a bond
conditioned upon the faithful performance of this Agreement, said bond to be in the penal
sum of $100,600.
b. Labor and Materials Bond. Developer shall furnish City with a bond
conditioned upon payment of all claims for labor and materials used or consumed in the
performance of this Agreement. Said bond shall comply with the laws of the State of
California, and with Title 15, Part 4, Division 3 of the Civil Code of the State of
California (commencing with Section 3082) . Said bond shall be in the penal sum of
$50,300.
3. Insurance Required. Concurrently with the execution of this Agreement,
Developer shall furnish City with evidence of insurance coverage as specified below.
a. Worker's Compensation Insurance. Statutory coverage as required to
cover the full liability of Developer in accordance with the provisions of Division IV of
the Labor Code of the State of California, and an employer's liability insurance coverage
with a limit of not less than $1,000,000 per occurrence to cover any claims arising from
employment not covered by worker's compensation laws.
b. Couprehensive General Liability Insurance. Minimum limits of
liability shall not be less than $1,000,000 per occurrence combined single limit bodily
injury and property damage coverage; any deductible provision shall not exceed $1,000 per
claim, and each :and every policy must contain a cross liability or severability of
interests clause.
4 ..:. c. Comprehensive Automobile Liability Insurance. Minimum limits of
liability shall be not less than $1,000,000 per occurrence combined single limit bodily
injury and property damage coverage; coverage shall include owned, non-owned, and hired
vehicles, and each .*and every policy must contain a cross liability of severability of
interests clause. ,::;
-1-
.£'v Lv4..J IIRiiti• fi �l.xI;. �,'[�"F+" ?' 4. _ s - }-•�, rF�T 25.1
d
d. Other R rements.:"' All insurance--poli shall!- beilssued_rby a
_ _._
.'company :legally licensed to try .act business in the State of L--lfornia',. shall be issued
at Developer's own cost and expense, shall be maintained by Developer in full force and
effect during the life of this contract, and .must have an "A.M;1 BEST" rating of B+, X or
better. All certificates of insurance shall name the City and'its officers, agents and
- .employees...as additional..' insureds, ,shall contain, .&, ,provision.`-that; a, written*-,notice.. of :._.:. ..
cancellation or reduction in coverage shall be furnished'the City (10) ten days in advance
of the effective date thereof, and shall state that such coverage is primary to any other
coverage of City.
4. Work Performance and Guarantee. Developer shall secure the services of those
skilled in the trade, profession, or calling necessary to perform the. work to be
accomplished under the terms of this contract, and shall guarantee and maintain the work
for a period of one (1) year following the, completion and acceptance thereof against. any
defective workmanship or defective materials furnished in the performance of this
Agreement, and shall guarantee and maintain the work for a period of one (1) year
following the completion and acceptance thereof against any defective workmanship or
defective materials furnished in the performance of this contract, and any acceptance of
the work by City will not operate as a release to Developer or Developer's bondsmen from
the aforesaid guarantee.
5. Inspection of the Work. Developer shall guarantee free access to City
through its City Engineer and his designated representative for the safe and convenience
inspection of the work throughout its construction. Said City representative shall have
the authority to reject all materials and workmanship which are not in accordance with the
plans and specifications, and all such materials and/or work shall be removed promptly by
Developer and replaced to the satisfaction of City without any expense to City in strict
accordance with the improvement plans and specifications.
6. Agreement Assignment. This Agreement shall not be assigned by Developer
without the written consent of City.
7. Abandonment of Work. If the work to be done under this Agreement is
abandoned, or if this Agreement is assigned by Developer without written consent of City,
or if City through its City Engineer determines that the said work or any part thereof is
being unnecessarily or unreasonably delayed or that Developer is willfully violating any
of the conditions or covenants of this Agreement or is executing this Agreement in bad
faith, the City shall have the authority to order Developer to discontinue all work or any
part thereof under this Agreement, and Developer shall cease to continue the work or such
part thereof as City may designate,- and CITY. shall thereupon have the power to obtain by
Agreement, purchase, rental or otherwise, all labor, equipment, and materials deemed
necessary to complete the work and to use such materials as may be found upon the line of
such work. Developer and his sureties shall be liable for all expenses incurred by City
for the acquisition and use of such labor, equipment, and materials.
8. Use of Streets or Improvements. At all times prior to the final acceptance
of the work by City, the use of any or all streets and improvements within the work to be
performed under this Agreement shall be at the sole and exclusive risk of Developer. The
issuance of any building or occupancy permit by City for dwellings located within the
tract shall not be construed in any manner to constitute a partial or final acceptance or _
approval of any or all such improvements by City. Developer agrees that City's Building
Official may withhold the issuance of building or occupancy permits when the work or its
progress may substantially and/or detrimentally affect public health and safety.
9. Safety Devices. Developer shall provide and maintain such guards, watchmen,
fences, barriers, regulatory signs, warning .lights, and other safety devices adjacent to
and on the tract site as may be necessary to prevent accidents to the public and damage to
the property. Developer shall furnish, place, and maintain such lights as may be
necessary for illuminating the said fences, barriers, signs, and other safety devices. At
the end of all work to be performed under this Agreement, all fences, barriers, regulatory
signs, warning lights, and other safety devices (except such safety items as may be shown
on the plans and included in the items of work) shall be removed from site of the work by
the Developer, and the entire site left clean and orderly.
10. Acceptance of Work. Upon notice of the completion of all tract work and
the delivery of a set of final as-built plans to City by Developers, City, through its
City Engineer or his designated representative, shall examine the tract work without
delay, and, if found to be in accordance with said plans and specifications and this
Agreement, shall accept the work and notify Developer or his designated agents of such
acceptance.
11. Patent and Copyright Costs. In the event that said plans and
specifications require the use of any material, process or publication which is subject
to a duly registered patent or copyright, Developer shall be liable .for, and shall
-2-
M S' t
.v......M1 •w i gak
1 .,.+r
indemnify City from, any fees, - -ts'or litigat ;an expenses, inc' 'ing .attorneys' -fees and
court costs, which. may result yin the use of patented :..copyrighted material; =
process of publication.
-12. Alterations in Plans and Specifications:`-::Any alteration orb alterations made
in the plans and specifications which are a. part of .this Agreement -or.,-any provision of
this.Agreement shall not operate. to release.any: surety.:-or sureties from liability on-any_
bond or bonds attached hereto and made a part hereof,:and consent to make such.alterations
is hereby given, and the sureties to said bonds hereby waive the provisions of Section
2819 of the Civil Code of the State of California. .
13. Liability.
. a. Developer Primarily Liable. Developer shall be responsible for any
and all loss, accident, neglect, injury or damage to person, life or property which may be
the result of or may be caused by construction,-.:operations, or execution of this
Agreement, and for which City might be held liable. Developer shall protect and indemnify
the City of Dublin, the City Council, the City Engineer and/or any officer, agent or
employee of the City, and save them harmless in every way from all suits or actions at law
for damage or injury to persons, life or property that may arise or be occasioned in any
way because of construction operations or execution of this Agreement.
b. Design Defect. If, in the opinion of the City, a design defect in
the work of improvement becomes apparent during the course of construction, or within one
(1) year following acceptance by the. City of the improvements, and said design defect, in
the opinion of the City, may substantially impair the public health and safety, Developer
shall, upon order by the City, correct said design defect at his sole cost and expense,
and the sureties under the Faithful Performance and Labor and Materials Bonds shall be
liable to the City for the corrective work required.
c. Litigation Expenses. In the event that legal action is instituted
by either party to this Agreement, and said action seeks damages for breach of this
Agreement or seeks to specifically enforce the terms of this Agreement, and, in the event
judgment is entered in said action, the prevailing party shall be entitled to recover its
attorneys' fees and court costs.
IN WITNESS WHEREOF, the parties hereto have executed this Agreement in duplicate
at Dublin, California, the day and year first above written..
_CITY OF DUBLIN
By
Mayor
ATTEST:
City Clerk
DEVELOPER
By Act
Coral D,6velopment Corpora ion, Inc.
3
5M"'� 7
std"
BOND NO. 9320565
iy TUM: INCLUDED IN
PAYMENT BOND L GE FOR PERFORMANCE BOND
(Labor & Materials)
WHEREAS,-- the City COUncil of'. the -City of —Dublin, State of California;~ and
CORAL GATE (hereinafter designated as "Principal") have entered into a
ontract under which Principal is to install and . complete certain designated public =_
mprovements, identified as project Tract No. 4415, City of Dublin, State of California, -
fiich contract is hereunto annexed and made a part hereof; and
WHEREAS, under the terms of said contract, Principal is required before entering upon
.he performance of the work, to file a good and sufficient payment bond with the City of
lublin to secure the claims to which reference is made in Title 15 (Commencing with Section
-082) of Part 4 of Division 3 of the Civil Code of the State of California.
NOW THEREFORE, we the Principal, and TNDEMNTTY COMPANY OF C:AT.TFCIRNTA a corporation
July authorized. to do business in the State of California, as surety, are. held and firmly
,ound - unto the City of Dublin and unto all contractors, subcontractors, laborers,
laterialmen and other persons employed in the performance of the aforesaid contract and
-eferred to in the aforesaid Civil Code in the sum of $ 50,300.00 for materials furnished
.Ir labor thereon of any kind, or for amounts due under the Unemployment Insurance Act with
•espect to such work or labor, and unto the Franchise Tax Board of the State of California,
:hat siad surety will pay the same in an amount not exceeding the amount hereinabove set
:orth, and also in case suit is brought upon this bond, will pay, in addition to the face
(mount thereof, costs and reasonable expenses and fees, including reasonable attorney's
:ees, incurred by said City of Dublin in successfully enforcing such obligation, to be
[warded and fixed by the court, and to be taxed as costs and to be included in the judgment
:herein rendered.
It is hereby expressly stipulated and agreed that this bond shall inure to the benefit
if any and all persons, companies and corporations entitled to file claims under Title 15
commencing with Section 3082) of Part 4 of Division 3 of the Civil Code so as to give a
:ight of action to them or their assigns in any suit brought upon this bond.
Should the condition of this bond be fully performed, then this obligation shall
)ecome null and void, otherwise it shall be and remain in full force and effect.
The surety hereby stipulates and agrees that no change, extension of time, alteration
)r addition to the terms of said contract or the specifications accompanying the saute shall
Ln any manner affect its obligations on this bond, and it does hereby waive notice of any
Such change, extension, alteration or addition.
IN WITNESS WHEREOF this instrument is executed in four counterparts, each one of which
Shall be deemed an original, and surety above named, this day of SEPTEMBER-, 1986
(Principal) CORAL GATE
By: -
(Surety)
INDEMNITY COMPANY OF CALIFORNIA
By:
EILA STEVENS ATTORNEY-IN-FACT
The foregoing bond was in open Council accepted and approved this day of
1986.
CORPORATION —
STATE OF CALIFORNIA CONTRA COSTAL Ss.
COUNTY OF I
On P 15 198 before me,the undersigned.a Notary Public in and for said State.
a SHEILA STEVENS
w personally appeared
personally known to me (or proved to me on the basis of satisfactory
W e evidence)to be the person who executed the within instrument as Attorney-
in-Fact on behalf of Indemnity Company of California, the corporation i
a '
F- therein named,and acknowledged to me that the corporation executed it.
y OFFICIAL SEAL
WITNESS my hand.aljtd official Seal. SUZANNE i0SLYN
NOTM PUBLIC CALNORNIA _
CONTRA COSTA COUNTY '
m My tommrsnon erpues Feb.26.1410
Signature /
I
ICC 304(REV.2185) This area for Official Notarial Seal
a• r:— n^,- .' -:a µ r 7 M. _ y nrvs..-s.r. — >.
_r
BOND NO. 9320565
PREMIUM: $3,018.00
PERFORMANCE BOND
WHEREAS, the City Council of the City of Dublin, State of California, and
rnudr rgT> into a
(hereinafter designated as "Principal") have entered:: : ..
ontract under which Principal is to install and complete certain designated' public
mprovements, identified as project Tract -No. 4415, City of Dublin, State of California,
hick contract is hereunto annexed and made a part hereof; and
WHEREAS, said principal is required under the terms of said contract to furnish a bond
or the faithful performance.of said Contract.
NOW, THEREFORE, we, the Principal, and INDEMNITY COMPANY OF CALIFORNIt corporation
my authorized to do business in the State of California, as surety are held and firmly
ound unto the City of Dublin hereinafter called ("City") , in the penal sum of
$100,600.00 lawful money of the United States, for the payment of which sum well and
ruly to be made, we bind ourselves, our heirs, successors, executors and administrators,
ointly and severally, firmly by these presents.
The condition of this obligation is such that if the above bonded Principal, his or
.ts heirs, executors, administrators, successors or assigns, shall in all things stand to
.nd abide by, and well and truly keep and perform the covenants, conditions and provisions .
.n the said contract and any alteration thereof made as therein provided, on his or their
)art, to be kept and performed at the time and in the manner therein specified, and in all
:espects according to their true intent and meaning, and shall indemnify and save harmless
;ounty, its officers, agents and employees, as therein stipulated, then this obligation
;hall become -null and void; otherwise it shall be and remain in full force and effect.
As a part of the obligation secured hereby and in addition to the face amount
;pecified therefor, there - shall be included costs and reasonable expenses and fees,
Including reasonable attorney's fees, incurred by City in successfully enforcing such
.)bligation, all to be taxed as costs and included in any judgment rendered.
The surety hereby stipulates and agrees that no change, extension of time, alteration
)r addition to the terms of the contract or to the work to be performed thereunder or the
Specifications accompanying the same shall in anyway affect its obligations on this bond,
and said surety does hereby waive notice of any such change, extension of time, alteration
)r addition to the terms of the contract or to the work or to the specifications.
IN WITNESS WHEREOF, this instrument is executed in four counterparts, each one of .
dhich shall be deemed an original, by the principal and surety above named, this 15th day
:)f 'SEPTEMBER, 1986.
(Principal) CORAL GATE
By:
(Surety) INDEMNITY -COMPANY OF CALIFORNIA
HEILA STEVENS ATTORNEY-IN-FACT
The foregoing bond was in open Council accepted and approved this day of
198_.
CORPORATION _
STATE OF CALIFORNIA
COUNTY OF CONTRA COSTA }SS.
On SEP 1 5 198b before me,the undersigned,a Notary Public in and for said State.
W personally appeared SHEILA STEVENS
EVENS
- personally known to me (or proved to me on the basis of satisfactory
w evidence)to be the person who executed the within instrument as Attorney.
a
0. �. in-Fact on behalf of Indemnity Company of California, the corporation
Q therein named,and acknowledged to me that the corporation executed it.
F-
y GXSbX,
WITNESS my hand and official seal. OFFICIAL SEAL
11ZINNI 1111,,
NOT-8Y PU8L1: CALIFORNIA
j' �r o�p,..✓ COWRA COSTA COUNTY
Signature My::�.:d;•raetp-,es Ed.26.19,o
ICC 304(REV:2/85) ntis area for Official Notarial Sea! t
N- C'j sJ'i � ,r.,'£..
.v .nNV`. - 1 i }fir: 1 :. 3 n.e. ... .. ., - e• .. .F. --.
NDEMNITY COMPANY OF CALIFORNIA �T
Home Office:333 Wilshire ,�,C 1� 510 988 3-
• Anaheim,California 92801 • (714)999-1471
POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS,that Indemnity Company of California,does hereby make,constitute and appoint
its true and lawful Attorney(s)-in-Fact,t0§91��xALti5v5L�t'and deliver for and on its behalf as surety,all bonds or undertakings if executed
before June 30, 1987;
and to bind INDEMNITY COMPANY OF CALIFORNIA thereby and all of the acts of said Attorneys)-in-Fact,pursuant to these presents,are hereby
ratified and confirmed.This Power of Attorney is granted and is signed by faccimile under and by the authority of the following Resolution adopted
by the Board of Directors of INDEMNITY COMPANY OF CALIFORNIA at a meeting duly called and held on the 16th day of August,1976.
This power of Attorney does not cover the following:
Bank depository bonds,-mortgage deficiency bonds, mortgage guarantee bonds, guarantees of installment paper, note guarantee bonds,
bonds on financial institutions, lease bonds, insurance company qualifying bonds, warehouse bonds, self-insurers bonds, fidelity bonds,
bail bonds,wage law bonds,and bonds of Ne Exeat or fiduciary bonds.
"RESOLVED,that the Chairman of the Board,the President,any Vice President of the Company,be,and that each or any of them hereby is
authorized to execute Powers of Attorney qualifying the attorney named in the given Power of Attorney to execute in behalf of INDEMNITY
COMPANY OF CALIFORNIA, bonds,undertakings and all contracts of suretyship;and that any Secretary or any Assistant Secretary be,and that
each or any of them hereby is,authorized to attest the execution of any such Power of Attorney,and to attach thereto the seal of the Company."
"FURTHER RESOLVED,that the signature of such officers and the seal of the Company may be affixed to any such Power of Attorney or to
any certificate relating thereto by facsimile, and any such Power of Attorney or certificate bearing such facsimile signatures shall be valid and
binding upon the Company when so affixed and in the future with respect to any bond, undertaking or contract of suretyship to which it is
attached."
NOTICE:1. This Power void if altered or erased.
2. Power of attorney should not be returned to Attorney-in-Fact,but should remain a permanent part of the obligee's records.
In Witness Whereof,INDEMNITY COMPANY OF CALIFORNIA has caused its official seal to be hereunto affixed,and these presents to be
signed by its President and attested by its Secretary this 23rd Day of April,1985.
INDEMNITY COMPANY OF CALIFORNIA
ATTEST:
By
Paul E.Griffin Jr. Secretary Jerome .Sweeney resident
STATE OF CALIFORNIA
COUNTY OF ORANGE SS.
On April 23,1985,before me,the undersigned,a Notary Public in and for said State,personally appeared Jerome J.Sweeney and Paul E.
Griffin,Jr.,personally known to me(or proved to meonthebasisof satisfactory evidence)to bethepersonswho executed the within instrumentas
President and Secretary on behalf of Indemnity Company of California, the corporation therein named, and acknowledged tome that the
corporation executed it.
WITNESS my hand and official seal.
--------------------------
t OFFICIAL SEAL +
� LAURIE 8. EPNER
Signature -e_ -
�- :�+a?NOTARY PUBLIC-CALIFCRNIA;
Notary Public i �''$ PRINCIPAL OFFICE IN i
Laurie B. Epner ORANGE COUNTY
'MY COMMISSION EXPIRES APRIL 22, 1988 +
STATE OF CALIFORNIA )
COUNTY OF ORANGE )
CERTIFICATE
I,the undersigned,executive vice president of INDEMNITY COMPANY OF CALIFORNIA, DO HEREBY CERTIFY that the foregoing and
attached Power of Attorney remains in full force and has not been revoked;and furthermore,that the provisions of the Resolutions of the Execu-
tive Committee of the Board of Directors set forth in the Power of Attorney, are.now in force.
Signed and sealed in the City of Anaheim, California, this 15th day of SEPTEMBER ' 1986
WARNING!This is a copyrighted document.Any unauthorized
reproduction is prohibited.THIS POWER IS VOID unless the
seals are readable,text is in brown ink,signatures are in blue f
ink and warning is in red ink.
�� ICC-2 Rev.6-30-86 Thomas H.Tyrell,Jr. Executive Vice President
RECEIVE ®
D,.E '3[(pTlrl[•T[ AMENDED MAP
INC UNKCM1ONt0. CORAL DEALO+N[Nt (ORPDRATION• A CALIFORNIA Llwi THE
►ARrKRS.t P. 00[3 KKe1
Cr THAT Tw[Y •RE TH( OWNERS O ALL Tw[LAr105 PUBLIC r/•� i/'�J
PW(AS[A(.T!D"'RE [D AHD[wfRAC[.VIT«IR THE (.T[RIOR OOPWOARr TRACT 4415 [ UB iC ��`�••RKS
INDICATE
IIA'O.THE Ht Or tw(w000ICO ilw•L .AP ENTITLED. '"ACT .AIS.
PL[AS"D TOP'S«Ip. •LAN[D•COwTY. [K IFDRr IA'. CONSISTING OF FOUR 1.1 /+
SHEETS. THIS CERTIFICATE 9(ING UPON SHEET I THEREOF, THAI THEY HIVE CITY OF DUB LIN
. C.US[D SAID.&P To K PREPARED FOR RECORD AW CORSE WT TO T,E ...INC ANO
AND ICONSE THAT NGTANOVFILING ETHCRECWI THAT SAID OE RA ►v CULAOO
SETS FORT. NO DESCRIBES ALUM LOTS 3-TE-010 FOR SAL[ /T .uRec••W ALAMEDA COUNTY, CALIFORNIA
THEIR PRECISE LENGTH ANo NIDTNI THAT SAID"AV P•RTICUL A0I SETS FOR;-AID
O
DESCRIBES THE PARCELS OF GROO'(SERVED ro'PUSEIC PURPOSES eY THEIR
.WW PIUMMER P ENGINEERING, INC.
w�04RIIic C�S.oEt"T' i-ATrs PARCELS OF QOwM 55S EASANTON, CALIFORNIA
/ .IRwSC [ xAPL c�o
AND DESIONATED As
CALLE OE CISAS.
AND TW[UWDERSIOKO. CORAL DEV[LO.K,ET CORPORATION. A C.LIIORNI•LIw1T[O .
►ARTKRMIP. DOES KRRT DEDICATE THE PARCELS Or GROIRO LYING VITwIN M
eOUPOA01[f O GAIL(K C•SA! IA PRIVATE STREET.) AS f0 OCS10.AT[0 AND rrNn[06nF NT - TOIRT[[
I(ORR[00, MNo TO TK[FUN IC-THIN I U11411 AND PLRPOOESROI FVOL IC wI WWATW.� SEAT[01 CALIFORNIA Ify
(PATE TY O 1 gILS R[FF RT[CRTII I[ATF
ANO THE UD[RSIGKO. CORAL BEVELDPREKT
CORPORATION. A[AL IF LORD L101 TED D„1.15 OAT OF
PARTKRf.IP, DOGS WREST RELIRROlIM VE.I R[ A[C[!6'10.(1 LORD 1-YO AND INS. O[FORE K. A NOTARY►UeIIC A SOILS REAOOT wf KEN PREPARED IM THE SUOJ[CT Su001V131ON OT 1I,E FIRw
KCOWTA SOA.[VARO AS MOWN UI"O SAID -H wA"1[D iMlflT I.AW UDR y10 COIMT ANO STATE. RERSO.ALLY APPEARED O T[PR.KIOCN. INC.. fOtl IOUXOATION ANO GL0.0GIGL (WINE[Rf.
ANOWR TO HE AI K THE O ,ASTER nC.IGAGE
•W M Upq[RSIGNEO. CORAL O(VELOVWNT COPPORRA TION, •CALIFORNI•LIRE TCD EO.o1NY, CALI" THE CORPORATION THAT [X(CUTEO TK FOREGOING STAT[HEri. REPORT OATLO, -WAIST. 1113
PApTKRMIP, ROCS HERESY O[OIC.T[ TO THE PUOLIC FOREVER. M 'IGNT TO AND ACRwONI[DGED TO HE THAT SAID CORPORATION EXECUTED THE THE. C[RT1F I[ lE M T,r [[aN O YHr fOARO OF SUPFRV ISORS
CONSTRUCT AND RAINIAIN"LIE UTILITIES ANO ALL APPVRT[HA . D THERE TO
UTTER. ON 00 OVER THOS( STRIPS OF LINO SHORP UPON SAID 1,.►. DESIGNATE RY CONHI33I0K EXPIRES,
•P,V.[.•OR PUOLIC UT II ITT EASCHENT THEREON AS EppNRACED YIT.Ir M 1. YI LL RAH C. K--"7; CLCRRI OF TT,[ ppARp OF SI/[RVISONS ON M co--O
EXTERIOR SOU1DARY UPON SAID maP AW THE NIGHT TO EKT'UPON SA 10 STRIPS O KAHED.. STATE O CAI IfORwI A. W HEREOF C[RT IIY Ab CHECA[D KLON. T«AT,
LAW FOR PURPOSES OF CONSTRyC'71NG AM HAINTAIKIN,PUPLIC 1(TILITI[S PRO N •PIPOWO WHO NIS BEEN FILED NITN THE SU•[RVISORS OF SAID CCl1NT
HEIR APPURTENANCE S. ANO STATE IH TwE •WOUHi oF [ CONOI TIowco FOR THE PAYN,[Ni or
IR TITHE f3 URNA[REOF, M {IND[RSION[O wK [R[CVRO THIS C[wT111 GTt OR WT•gT PUeIIC Ir •NO FOUR SAID ALL TARES AHO SRECIAL .SS(b'HE HIS[0.l[CT[0.S iAX[S Y.I CH.RE HOi
THE
DA O INS. COWTT AW SIC IN LIE« A AINST SAID LAW OR A.Y PART TMP[OF. OUT WT It T PAIAfLE AID
w1 00.1 A►PNOV[0•♦ LIO BOARD O SUPA[RV I3ORS IN SAID AW,OP,T.
ALL TAXES AND SPECIAL ASS[SSHENTS COLLECTED as TAXES HAVE PACE. ..to K
CORK 09VILOPKKT CORPO0ATION, A CKIFORNIA EMPTIED►AOIKRSNI►. uON •.rrR"I'll-Tr CERTIFIED OT INC TKASUR(R-T AA COLLECTOR OF M CWAT OF ALAR[DA.
1
1• SHE lw0[RSIGNCO. VINCENT H. CRPN,A. 00 HEREBY CERTIFY TWAT 1 AN i-[ IN WITNESS THEREOF. 1 HAVE KKURTO SET HT NANO THIS DAY O
LIC[.1CD LINO SURVEIDR RESPO SleL( LOP THE SWVL.S FRO'WHICH THE N[p[Ir INS.
BY, I.w00I[D Fl.AL-AP t.TITLEO -."(.OED wAP, TRACT .AID. CITY OF WBI IM.
K ANEO• COV,RTI. CAL•FORNIA.AT[•OOif SIRPV(�DYASTI[eRUART.K1/fIS1TwE TFOII
%.to IIY.L wAPt
PIT, SAID SVRKT WAS HAD[ UHNOCR AI DIRECTION, IH.1 SAID SURVEY IS TRUE AND
CCHHH.(I( AS S.OW«1 THAT Twll[[PTIF ICAT( ATT[ST1.G i0 SUC«SURY[♦ nA5 WILL IAw C. 'W:Rw.L IN. CLERK d TNC
K[.PLACED ON SK E7 I ON SAID FINAL lap WNIEH CONSISTS O<LOUR TAI OOARO a SURCgV ISOOS Or THE COtYNT p
yLIINOU,E[DGYRyT SH(t TS, T„AT TwL fOUHOAPI RONUw[Nt!ARE O THE CNARACTR .W OCCUPY TM AA—10A. STAY[W CKIIORRIA
NE)l I11DNS IW ICATCD'ON THIS N•P AHO WILL K SET
YIT.IM
TWO It r[IRS OF
STATE DF CALIFORNIA ly y
THE DATE W ILL INo Or ?.IS Par. AND TRAY Salo RONUHERTf WILL It
CpMT f ) SUFFICIENT TO I—BLE THE 1W tv TO PIE RETRACED. yY,
DERRY CLERR
ON THIS DAI O' 1111. KFORE HE SIGNED THIS_PAT OF 1111. U .
A DTAR/PUOLIC IX 1UH0 FOR SAID STATE. ;If AL ♦ APPEARED FIT[,Ip.'a RT 11 I[ATL
AND KNOWN TD HE 100 PROVIDED 16A SFACTDRY [VIO[NC() TO
0E M ANO SHE O' THE LIN T[0 1. RICHARD C. A"&gOSE. CIT LE[RN OF M CITY O DUBLIN. COUNT O
PAgTHERMIP T—EXECUTED M YI T.I. INSTRUWKNT ON BEMµ/ OF TRW[ LIRE TTD VIK[.l R. CWNA. L.S. W• AS(0 ALmm DA. STATE OF CALIFORNIA. DO Of CERTIFI THAT THE HEREIN Ene00IED
PARTKRWIP HEREIA rAHEO AW IDCWWL[OO[O TO K THAT SUCH LIw ITIE FINAL RAP ENTITLED'AHEW[O NAP. TRACT 4.15. CITY OF OWLIN. ALAHEO•
PARTKRMI►EXECUTED M LN[. COUNTY. CK IFOPWIA.• CONSISTING a IOW 1.1 SHEETS. T.IS[['T IFICATE
_ OAT[OF EXPIRATION. KING UPON SHE[I I TQREO, WAS PRESENTED 70 SAID C171 COUNCIL AS PROVIDED
11 LAY AT A REGULAR KETIW HEREOF HELD ON M _DAY Or
111, rHG1.[rR'% CERTIFICATE INS. AW TVAT SAID CITY COUNCIL DI0 THEREOF. By RESOLUTION W.
NOTARr NUDE IC IN AW r0R THE COUNTY OULI PASSED AND ADOPTED AT SAID K[TI G. APPROVED SAID HIP. AW DID RE.lER
O STARE D/ t. LEE TWN►SON. CA [W INEtR FOR Tl,[ CIT O W1l IN, COUNTY d AL.HED•. ON eENKF OF THE PUOLIC M OFFER O DEEP ICATIO.0 LAWS OCSI WAT[D AS
CAL IFOMNR♦ yT•TI O CALI/ORAL IA. 00 HEREe1[['TUFT THAT ALTER Aw[XAwI«ATION O THE •CALL[ BE GSAS• (A PRIVATE STREET). •►.Y.C.•OR •RHIIC UTILIT
FINAL AAA ENTITLED •AKWEO..P, TRACT .115. CITY O OUOLIN. ALAR(OA LA PERY•. •►.A.[.•ON PURIIC ACCESS EAS REWT. •A.E.• OR •ANbNDR
wY CORNISSION EXPIRES, COUNTY. CALIFORNIA.• CONSISTING OF NOR TAI SHEETS. THIS E[III SIC.TE
KING VPU7N,lNECT 1 7HER[O, I .AV[ IOUPO THAT THE SUf01 VISION SND,WN O. [AKHEKT•.
S•ID wu TO e[ SUfSTINT1ALlr THE SAN' AS 1.10 NMOIVISIGN I PIE.►Eo 0.THE
TTNwTr•a CERTIFICATE TENTATIVE H•P APPROVED THEREOF 1NAT 'AID FINAL III CORPLI[S WITH T..r
_ PROVISIONS OF M S301VISO,wAP ACT 0101 STATE OF CALI/ORRIA/DAY[
RASTER IDRTCiAGE Cv ^— A CALIIO«RIA CORPORATION. AS T1NS7EE UDER M ARE«OHENIS THERE TO AND O ANY LOCAL OROIN•.CE APPLICADLC AT THE T*a0 .
OEEO O TRUST RECWO[D AAII A. INS. 3[41[3 W• N-O!•1l1. AL.NEDA COUNT APPWgvAL OF SAID TENTATIVE HAP.W TwT 1 AR SATE 3.1[D THAT SAID R✓ IS glC«ARD C. AwOWSL
RECORDS DOES HER eT ,DIN IN AW CONKRT TO M IOREDOIW OWNER T[CR.ICALLT CORRECT. CIT GCIM
Crall KATE.
1 it WITNESS THERE., 1 HAVE HEREUNTO SET Al HAW THIS�DAY
RAf?"PC'TOAK CON►Aw1 . INS. K R'a CERTIFICATE
ST, FILED THIS�DAY O INS. AT .X. iN
by, LC( TNC PSG. SOOT of wA►y AT RAG[ AT THE KOVIE IT OF
CITE ENGINEER FOP THE CITY O DUBLIN.
TITLE, COUNTY (W, At AKDA, STart O CALIFOI.IA.
R.C.C. N0. KK C. DAVIDSON. COUP'"CLEM/RECONDER
Dar[ OF EXPIRATION. bT, BEpU`TV
ERIK W. FE[
Ott C B b' s
AUG � 1_ 1986
AMENDED MAP
° Cq.,T :'� • TRACT 4415
ALAMEDA AS Sl•OWN IS AS. EO"�°" �"° CITY OF DUBLIN
pETWEEN TK CQNTIES OF ALAMEDA AMD .
CDKTRA COSTA PER LETTER FROM ALAMEDA .
.QTY SURVEYOR DATED DECEMBER'.."i° / ALAMEDA COUNTY, CALIFORNIA
T` G 1 GC)Z), PLUMMER 6 BABBITT CIVIL ENGINEERING,INC.
to MAIPEPfosT -Sa A A �( PLEASANTON, CALIFORNIA
a00to w,pp01 ANA
/ s.PIE a&% OF BEARINGS
/ O ,usp��,,.`�t .� >1:1,2 MONUMENT LINE IN DAWNA DRIVE AS
SHOWN 0, TRACT BOOK 5 OF
.JULY 20, 1962 IN BOOK ♦S OF MAPS,
ey�0• Gam" R 7SOO, 7 � AT PAGE 54 OF ALAMEDA COUNTY
` Ai OFFIGAL RECORDS, TAKEN AS
_,rp• p•� r y O �° N 16•DY 56�W.
W" p • � fuLE,I••�p•
vo- ,•moo.: N
,.•i N
o�
/vC
O 11`
y�7' LEGEND,
O.SET 1 V2'I.P. LS 4520
4 ,yj O SET ALAMEDA Ca STO.MONJ.ENT
L, •NF �j ,'` U A.E-ANCHOR EASEMENT
lv Zg L\ 0 Q N P,U.E-PUBLIC UTILITY EASEMENT
J : T^�-• T� N O- Fn STA ALAMEDA COUI STREET MOK1•IENT
, AIOMVENKSlIAR ACCESS
E. .
Y e,t
0 PA. pAL4 AC—EASEMDIT
20 ' ` Y R.'O? \ 9y E7CTEIBOR DOWDARY LINE
IS
%
•X10 r. P
L 0
2 dtiT� 1 SO �a fi. AI .F•
VI OfFEA y �O » b SCAU.I.D
G /A
o ,E � \
2 ��a,e• ` ,\ „N. Nom.
27 ,O 4
�O'O/F JL SC Sy•A)11f Y1
E ��G �AC� SHEET 2 OF 4 SHEETS 0.
R E C E O V E D
AUG 111986
86
ISEE 9 SHEET 2 OF 4 FbfHP -1'`111"t�
�� � Z&OO' s AMENDED MAP
2 362.25' z<oo 0.12.1s3s
NIC'DT36w _. W p. 24r 38 TRACT 4415
26 Dn
1
i.2.3T ry I^
=E CITY OF DUBLIN
'�
x+ °fi � •ti«
��
S
po
•$o 2, ALAMEDA COUNTY, CAL
IFORNIA
ERING,INC.
.�' 22 Z ' IW
" j�< PLUMMER 8 BABBITT CIVIL ENGINE
. D �6 w
z z VL PLEASANTON,CALIFORN IA
cooe C s
FI ax _. ==p = E
f Oato SS = 2000-
, Z f,. 400•— •= .. R.211.
2noo —_ ^•,+ I L•a&o*1 BASIS OF 8EQR1NG5
W --�«apu710M .- l:}C i I -y MONUMENT LINE p/ DMIONA OITY[ AS
NW •�— R 1 I 3/ SHOWN ON TRACT 2289,FILED
22•RUL A70°FFE MN.M��2as.a�_- •a 3 ?_I f JULY xo, Acz IN eooK 45 of wus,
" T16 '"p,5A.5trwltAiE aT T _ --•tom` {Ct I AT PAGE 54 W ALAMEDA COUNTY
CALLS C wNr 0736 rr J �� OFFICAAL RECORDS, TAKEN AS
.�� "'— N16 07'36•M J �A `•� •1149 I I I 0 0 N N is-D'YSd'w
•�,� 1 in I I auLE Wed
•
g W
05A1L •A• _ °d YI� I wa I I 1 —
�"���•
i { K
to O N 5-41A
'2000 i 62 C,9 ,Z„ b • $iil¢
QQQ^ 3 • W O plr
`.32.00•IOTAL � 7' 'M 44.0 .._� U'•p17 RI I O a •lC�l
' •
0 W O I I
��o w LEGEND
0
2T $ =I i i 'o ti..., O• SET I v2'1.r LS 4520
z / a(
'OBE •. I I U !• SET ALAMEOA cn STD.MONUMENT
• 1` ��� z "Sfi' 3400' M I•• I Ev
N�•OT SCE? �•t3']OY Sa.00 N,t7C7� •ga I n '^ �m A.E.•'ARC NQR EASEMENT
'I L•0. y8 4 y1I - ( '[�' ?U.Ef PUBLIC UTILITY EASEMENT
�y 1.1— LDO I I }--u�11 ��MDN vsHwuR nocESz
z 0.30 " �. �t'0 14.00 '11
N •23. _ N Ii39 K w ! CE lA i j7J 1
S %
I'll I . o
96 o 1 ry ^
�I
ERTERIOR OOVSOART UNE
16.
41
PLL Mo CFFE71 of OEDICAtm
N11• •6'w �- 42.70'
N DETAIL•B•
CALLS OF CASAS"rj&TE STREETI I 14 / —I f� Y NO��
NU•SaCb'_, w 7 —y-----
'4 I I tl73Z44 �R1
_. •� �. v =ay I
50 oi
4
1'N 79'OI'14•E IRI v I • b3]•01�r1
Z z Z i ., 6 600 F 35 I�.6TH 51• t .c..e,. 8.24.3'
z6D0 i00s ¢p pp z z 27 I 1 R.I6S n 0 r% N 7]3204•E L•22.7Y� p•2D'
1 1 'z 6 0= 5 1 L•21�4' u•-.0^7 I .179
%1! a 10 8 6 s $$ e g-_ 7 8 I ' g N soT-�sYlaw
. iLF n7 w0 r^ ^0 • zr/ N73.32'Olt E
_ •Ib • .�. I 1 \ tDt M 16.OY'St:w � I �
M7E•I'1•A'F II
c,Sn , 10' RUL SERIES ATY7732. DR. MAPS F634 --- --.— --- ---- 1 p•2Y42'3T� N .- •y NSY00'Oa'M IRI
--- ———- 2100' 2600' 2600 •4 —�, R•2 Od '00!
sbao' z600' jXOd . 1J1!1^ L•ne r $, —
yLi•' )4).13' 70TAL tlOUNDART N 76.13•SOt 1 '�- 2239
STS OFCALIr�JRNIA N 11'3a'K'w NON•YE14CtLARAOCESS °��4.0 aaDy'"TO zzSe
SHEET 3 OF 4 SHEETS
AW42457MARCHIO-J-4 04AL.A060
z(o-ONO
• • 4 Cl 4� c i. W V
` AUG 111986
PHRI rr %A
CG
gT>,TNECDNIa �,�•R.I�eETWEEN AMENDED MAP
XSSHOW CtSASAAIODU"RA yAN TRACT 4415
ALCOSTA BLVD. �S UPON�
CONTRA COSTA PER LETTER FROM u e•Fta
OOWTY SUR`E1OR 04iED° ""96O• CITY OF DUBLIN
"°r"E"'"'"" ALAMEDA COUNTY,CALIFORNIA
CONTRA COSTA COUNTY Nai's2'oat Ioa4A sel.00 7atoA
-- --- 7�T/•I / PLUMMER 6 BABBITT CIVIL ENGINEERING,INC.
AMrDA COUNTY o 21DO
AL
n ON` PLEASANTON,CALIFORNIA
mTrw
060 A I T+ It 8,00 I 2a BASIS OF BEARINGS
OA�di\�\1q�,ef,- , ���A 1 i '' 27 J.2 j MONUMENT LINE IN DAVONA DRIVE AS
�� o. 6 S SNOWN ON TRACT 2209,FILED
VIA ?.Y1�E t�i� JULY 20, 1962 IN BOOK 45 OF MAPS.
i
. �O4 C /y�OA ice. •t�E \� .f ''11z AT PAGE 54 OF AIAMEOA COUHTT
w yi 1,T1'i0 °.$ ti i� 9 I 10 A OFFICIAL RECORDS, TAKEN AS
• , W j i� o°. \A s6ap�$ �• /I i _ stALL:1'•20' N 16'07'56'W
N 7
►� ,, .:~
4 ��-.
I ,z.0o
Z8
O I 14 00 O SEE SHEET 2�
0 o R . Na! 04 E 1.
t of �/ �� 05- _; •2 9!9' ti �� o
�g ,nT9 R•2430'. �\ o rI IN 7J'YOa'C I9 I �i
Cg f e0i �o �6j�0iC C.x.fi �I oI o o LEGEND:
j 1 -•�fi �•` M!5 \ �I 0 I O SET 11/2"LP. LS 4520
u P� F• I ,F / O SET AIAMEDA CO.STD.MONUMENT
I^ - /p,9!'x50' 711.0 11_001 N W E 60.00
!! u !///! NDN-VCHICULAR ACCESS
> I I nI I « ��...�ExTL0 6QD4RY LNE
7,'#O�
27 I g
6G
4G0 n
N T•S204'E
N 7tQI'1at IRI
�g 1 Y�I� �. Q
4 I ; • 2,c �j u I�i,. b zo 8 za
12
Al I "1� �� >7 S w5t I, 1 I I I 19 A•�7'x2c
Ny"$M E •yy x.00' C 1A s R. 19.70• /
Nlsafw of b o e D o Ip tl f►« W I� I g± L•2115 .
11 8 Zl r r !°�I u 7 J I pat 21 I :
I e a. 1 r-1 t 7 J I 14.00 g IL
6100' Q• • 7�=J DETA IL o C, I Q 42.00' ►UC.
l a. J 1v U IMe'J17A\R .N
N a7.01 w E 1
I
'o I I � a z g I r--' 1 1,
I )0 i I u l SEE SHEET 3 I _ I i 22 I ��.o .o��►
t a C
w eY 9-01
ETO aL•o•IP118lK; UnLITT
EASEMENT)
SHEET 4 OF 4 SHEETS
c�
V
G� TRACT44/S K��BALL
A3f4 D
WAY ep °may
y o
c DR.
pAV4HA •
680
_z
✓✓0 sCAL E