HomeMy WebLinkAbout4.1 Amendment No. 1 Village II Improvements q10 - �
CITY OF DUBLIN
AGENDA STATEMENT
City Council. Meeting Date: July 27, 1987
SUBJECT: Amendment No. 1 - Tract 5511. Agreement
Village II Improvements
EXHIBITS ATTACHED: 1) Tract Developer Agreement - Amendment No. 1
2) Performance Bond in Amount of $648,381
3) Payment Bond in Amount of $324,191
4) Location Map
RECOMMENDATION: V Approve Amendment to Tract Developer Agreement for
Tract 5511 and authorize Mayor to execute same.
FINANCIAL STATEMENT: No cost to City. Cost of inspection is paid by the
developer.
DESCRIPTION:
Tract 5511 "Villages at Alamo Creek" was .originally subdivided as a
master tract, dividing the project into seven units, a commercial site, creek
parcels, open space parcels, and parksite parcels. The single-family portion
of the project was also subdivided with the master tract. The master tract
improvements included the creek work, Dougherty Road improvements, the
southern loop street, and all streets within the single-family area.
As each of the remaining six units of this project are developed, either
an amendment to the master tract agreement (for Rafanelli and Nahas projects)
or a new agreement (for other developers) will be required to cover the on-
and off-site improvements for these individual "Villages."
This is the first amendment to the master agreement. Village II is
located at the northwest corner of Amador Valley Blvd. and Dougherty Road.
----------------------------------------------------------------------------
ITEM NO. COPIES TO: Rafanel.l.i and Nahas
t
FJ "T 27
J'A
YK
Y
-Tj 1.7
C
CITY OF DUBLIN C
TRACT"DEVELOPER AGREEMENT:;-.4-
-,"AMENDM E NT,:10"; '1
Wo RkS
TRACT ,
'5 bbl
-.II 14 9
VILLAGE :IMPROVEMENTS.-'(LOT;,
(Cottonwood..:Circle)
This Am 6nd s made , and 'entered,' into
th ayc
f-
d.:_ ' '1987;
by' and Dul
municipal corporation;- hereinaf ter cref erred lfto:-Yas "CITY"..,
Ra f 1 .4 h
ane .Na as .,hereinafterl.referre as '-,"DEVELOPE
o
W 'I .........
-T N EIS :S :
E T ;H
E y Council f the" C I'
;California, Developer,, 'er _V'
6 i ni "d h e 1 o p e r �'as .-a into'.a
„the };subdivider;,��:entered
zzl r ac t
Developer.i'�Agr5eem e' 'nt 'f o r'; tbe"-'Master :l,
ract.- Lmprovemen t
s
withrin Tract 15511 on S ept em b er
E3
0 --construct,.!-u a
WHEREAS,'�'�-,�,,D eve 1 oper --in'* tends :t r),
--cond o"m"`n" I.,u-m--"'.p'r-oJ'ec'
t :.as,-
provided ded - or,
n I:t h-
e :'m
ap' •
ct..:_5511:
and
to improve-'certain0 -.149 ::'improvements I n :keeping,:.with
requi.r.iiie)n ts';and .conditions*. set ' forth ' Ithi !-th
e �City
-of:"Dublin,'.�..:City.% Counclit'Resolution -.30-86
:(PA85 041 .A. "and 2 '1,and:-_-Tentative
Tract,,,,,6.5.11 )'.:" "a'd6p't 'e*d .'on March'-24,' 1986; :=and ,:in accord' %
..with
those �,certain 'plans and specifications 'for .-.said -Lot --:449 %.(Village
IIF ,:Cottonwood) :--'on file in the office -':of.-..the CityEngineer '-which
are .,herebys.,re'ferred to for, amore definite and -distinct.
description"'of-..:.t he..�.work to be performed under -'this '.Am6ndment '-_No.
6u' g' h".se't;.'fo'rth at length herein;1 -as .,:th n; -and
WHEREAS,'.% Developer Intends to ' of fer`.for : dedication storm
drainage facilities, public utility easements and emergency
vehicle . accesst.easements .within said Lot , 149 ;* 'and
WHEREAS, ' Developer intends to satisfactorily complete the
required Improvement within the time hereinafter specified, and
City . intends to accept some and reject other of the -Developer ' s
offer( s) of dedication of said Improvement (s) In consideration
for Developer ' s satisfactory performance of the terms and
conditions of -this Agreement ;
NOW, ' THEREFORE ,' 'in consideration of the mutual I promises,
conditions. and covenants herein contained, .the parties agree as
follows :
i . : * Improvements SubJect to this Agreement . The Improvement's
subj.ect to this -Agreement shall include all grading within Lot
4
149 , construction of storm drainage facilities , ' street
Improvements within':Cottonwood -.Circle'And;'oPf-site ,improvements
including a right `hand ::;turn-holding .:Iane.�,at'�Dougherty Road ,and
Dublin Boulevard,''; `a':,traffic ;signal at Amador'Nalley Boulevard 'and
Dougherty ' Road, ' a soundwall -'%abutting Lot '149 along Dougherty Road
and Amador Valley Boulevard 'and 'landscaping between ;.the right 'of
way of Amador Valle y...BouIevard and _Dougherty Road
soundwall , . all of which shall cons tItut"e -`Lot 149 improvements . . '
2 . Separate Agreement:'_" This '.Amendment shall form a separate
-- and.,complete --agreement-i°regardirig :_the ';improvements :.wi thin '.Lot .149
and shall :not serveYto``extend :`or::.otherwise modify: Obligations of
the . Developer .--.under`:�-theMasterTract .Improvements 'Development -
Agreement referred tto''above = The" obligations .under :;this
Amendment -'No ; ,-1 are;�separately';'secured :as ', provided herein .and
Shall :not . effect ,-the :Release',-of security. .for the' `improvements
provided ' for in .:the' Master Tract .Agreement . =/ =
3 . -. Completion Time.Y4Developer'.will complete the work
:..
required . by::this Agreement:,.,within -.--'a .timely ;manner .-following .the , `-
date :.on' which` City executes :this „Agreement Developer :shall
complete :.said :work f not W_later:{than -one year:.following-;said date of
execution. ::- Time`' is`of :;t he"essence ' in .this °Agreement . Upon
completion,'-, Developer: shall:-furnish City with a complete and
reproducible set -of fInal_'.as-built: plans , including any.
authorized modifications � '<;;;: ::;. .
4 . Security Furnished . Concurrently with the execution of
this Agreement , Developer::shall . furnish City with bonds, or other
acceptable security,-:'':securing faithful performance and labor and
materials . Such bonds ,'. or other security, shall be in a form
prescribed by City: . The bond, or other security, shall become a
part of this Agreement : : . .
a. Faithful" Performance Bond. Developer shall furnish
the City with a bond conditioned upon the faithful performance of
this Agreement . Said bond to be in the penal sum of $ -� ,/
b. Labor and Materials Bond. Developer shall furnish
the City with a Bond conditioned upon payment for labor and
materials . Said bond to be in the penal sum of $__37s _.
b . Insurance Required . Concurrently with the execution of
this Agreement or prior to. the commencement of any construction,
Developer/Contractor shall .furnish City with evidence of
insurance coverage as specified below.
a. Worker ' s Compensation Insurance . Prior to the
commencement of construction, statutory coverage as required to
cover the full liability of Developer in accordance with the
provisions of Division IV of the Labor Code of the State of
California, .Nand .an • employer ' s 1ability' Insurance coverage with` a
limit :of --not "less .,than $100,•000 per,�occurrence ! to ':cover .any
claims arising from employment ,,not ..covered :by..worker 's
compensation -laws
b. .-.;Comprehensive -General �Liability-'Insurance Minimum'-.
limits of .liability ;shall not ..be,. less ,:than :$1; 000,000 _•per,
occurrence ..combined single limit.-.bodily injury and property
damage .coverage;.;any :deductible `�`provision -.shall :not --.exceed $1 ;000
per claim,"'**and ,each 'and :every.-policy must ::contain across
liability. or.-severability ;;of _interests;_`clause.
c .Comp rehensive::Automobile 'Liability Insurance
Minimum 'limits of....liability.. shall _be•_not-:less .-than "x.$1;000 -000 per
occurrence . combined :single.`limit : bodily'.:-,i.rijury._and ,property
damage .coverage;:`coverage:� hall = nclude":!:owned;."non-owned ".' and
hired vehicles ; :.and :each`: and every:.policy,must contain-a cross
liability --or severability `of ='interests =clause:
` d :Other Requirements All': insurance policies shall be .
issued ..by . a :.company --legal ly:.licensed ;;:to ;.transact business An the
State of :California; shall...be -issued �`at Developer's own cost and
expense, :.shall .be ..maintained ,bY.Developer an full force and
effect during- the life oP:.this.. contract,":.and must .:have an "A.M.
BEST" .rating of .:B+, '.X or ,!better: : :All `certificates _:of "'Insurance
shall name the City and Its off icers ,,= agents -'and :employees as
additional insureds, -:shall contain a =provision that a written
notice of 'cancellation or reduction -in -coverage shall be
furnished the -.City ( 10 ) - ten days --in -advance of the effective date
thereof , and -shall state that such coverage is primary to any
other coverage of City.
6 . Work Performance and Guarantee . Developer shall secure
the services of those skilled in ;the trade, profession, or
calling necessary to perform the work -.to be accomplished under
the terms of this contract , and shall guarantee and maintain the
work, for a period of one ( 1 ) year following the completion and
acceptance thereof against any defective workmanship or defective
materials furnished in the performance of this Agreement , and
shall guarantee and maintain the work for a period of one ( 1 )
year following the completion and acceptance thereof against any
defective workmanship or defective materials furnished in the
performance of this contract , and any acceptance of the work by -
City will not operate as a release to Developer or Developer ' s
bondsmen from the aforesaid guarantee. The amount of the
maintenance bond, following acceptance of the work, shall be
25% of the amount of the performance bond.
7 . Inspection of the Work. Developer shall guarantee free
access to City through its City Engineer and his designated
representative for the safe and convenient inspection of the work
4
.."'throughout its 'construction `Said :City ,representative 'shall ` have
the authority to reject all materials ;and workmanship;which are
not In accordance with the plans and specifications;-�;and-aII such
materials and/or work :shall :-be .removed promptly`: by_::Developer and
replaced 'to the satisfaction of •City without-.any;;,expense. to City
In strict accordance with the -.improvement -plans =and
specifications . J
8 . Agreement "Assignment . -This 'Agreement 1shalYl":not -.be
assigned by Developer -without the -written- consent -- f ..'CIty.
9 .`.: Abandonment of Work. If ahe work 'to be done under ...,this
:*;. .
Agreement is abandoned,•:• or :a f this :;Agreement-`Yis.,assigned =by
Developer without written •consent :of ..City --,, yCity<.,through 'its
City Engineer determines .that :':the =said -iwork or'any_part';whereof
is being unnecessarily : or unreasonably .delayed.�o,r that ''Developer
is willfully violating .any of -the conditions or-,covenants :of. .this
Agreement or is executing this Agreement ; n tbad-:,;faith`;-';;the`.City
shall have the authority to order Developer1'to: discontinue ::'all
work or any part thereof under: this :_..Agreement;7andDeveloper _ .
shall cease to .continue ,the ."work"or .such:`part whereof as City _may
designate, and City shall ,:thereupon have. the power to. obtain t by
Agreement , purchase, rental or otherwise, `.all;aabor; '.equipment ,
and materials deemed necessary :to complete :the;work-and to ±`use
such materials as may be .'_found -upon '-the line 'of:=:such'."work. --
Developer and his sureties shall be liable for all expenses
incurred by City for the acquisition and use. of such :labor ,
equipment and materials. _
10 . Use of Streets or Improvements . At all times .prior to
the final acceptance of the work by City, -the use of any or all
streets and improvements within the work to be performed under
this Agreement shall be at the sole and exclusive -risk of
Developer . The issuance of any building or occupancy permit by
City for dwellings located .within the tract shall not be
construed in any matter to constitute a partial or final
acceptance or approval of any or all such improvements by City.
Developer agrees that City 's Building Official may withhold the
issuance of building or occupancy permits when the work or its
progress may substantially and/or detrimentally affect public
health and safety.
11 . Safety Devices . Developer shall provide and maintain
such guards , watchmen, fences, barriers, regulatory signs,
warning lights and other safety devices adjacent to and on the
tract site as may be necessary to prevent accidents to the -public
and damage to the property. Developer shall furnish, place and
maintain such lights as may be necessary for -Illuminating the
said fences , barriers , signs and other safety devices. At the
end of all work to be performed under this Agreement , all fences ,
barriers , regulatory signs , warning lights , and other safety
devices (except such safety "Items as may be shown on the plans
and included in the items of work) shall be removed from site of
the work by the Developer , and the entire site left clean and
orderly.
12 . Acceptance of Work. Upon notice of the completion of
all tract work and the delivery of , a set of final as-built plans
to City by Developer , City, through its City Engineer or . his
designated representative, shall examine the tract work without
delay, and , if found to be in accordance with said plans and
specifications and this Agreement , shall accept the work and
notify Developer or his designated agents of such acceptance .
13 . Patent and Copyright Costs . In the event that said
plans and specifications require the use of any material , process
or publication which is subject to a duly registered patent or
copyright , Developer shall be liable for , and shall indemnify
City from, any fees, costs or litigation expenses, including
attorneys ' fees and court costs, which may result from the use of
said patented or copyrighted material , process or publication.
14 . Alterations in Plans and Specifications . Any alteration
or alterations made in the plans and specifications which are a
part of this Agreement or any provision of this Agreement shall
not o e at tottrelea a anyy financia institut on f om liability
ro ma e�ssucn al eratlonsris°herebyag�ven, and He°linanciagnse t
institutions hereby waive the provisions of Section 2819 of the
Civil Code of the State of California.
15 . Liability .
a. Developer Primarily Liable . Developer shall be
responsible for any and all loss , accident , neglect, injury or
damage to person, life or property which may be the result of or
may be caused by construction, operations, or execution of this
Agreement , and for which City might be held liable. Developer
shall protect and indemnify the City of Dublin, the City Council ,
the City Engineer and/or any officer , agent or employee of the
City, and save them harmless in every way from all suits or
actions at law for damage or injury to persons , life or property
that may arise or be occasioned in any way because of
construction operations or execution of this Agreement .
b. Design Defect . If , in the opinion of the City, a
design defect in the work of improvement becomes apparent during
the course of construction, or within one ( 1 ) year following
acceptance by the City of the improvements , and said design
defect , in the opinion of the City, may substantially impair the
public health and safety, Developer shall , upon order by the
City, correct said design defect at his sole cost and expense,
and the financial institution .under _the bonds shall be liable to
.
the ,City 'Por , the .corrective work required.,
c. Litigation Expenses . .In :the_event '.that `legal •action
.instituted by either .party to .this°.Agreement;`;,and ;said :action
seeks ,damages for breach of this 'Agreement :or :2,aeeks to "f :->;:''
..specifically enforce the terms .of .:this :Agreement, ;and, in the
event judgement is entered in said action, the -,,prevailing party
shall be entitled to recover -its :attorneys '.,,. Tess -*and _..court costs .
IN WITNESS WHEREOF , the parties hereto have :executed this
-,Agreement .-in .duplicate in Dublin, California, .the day and year
first: above written. "
CITY OF • DUBLIN
By.,.
ATTEST
City Clerk�� Yr-
DEVELOPE��I,'�•(/�.�s
By: �: ✓
•
AF vi s FD
5/2 vb,7
No.*'*. 86525
4/9/87
PAGE 1 of 3
CITY BOND ESTIMATE
VILLAGE II - COTTONWOOD
WILLOW CREEK
ITEM QUANTITY UNIT PRICE TOTAL
STREET
FINE GRADING 166,504 SF $ _0.15 $24,975.60 .
CURB 8,646 LF 7.00 60,522.00
CURB & GUTTER 810 LF 10.00 8,100.00
3' VALLEY GUTTER 2,435 LF 9.00 21,915.00
TEXTURED PAVEMENT 7,250 4.50 32,625.00
PAVEMENT (PARKING)
(2/10.5 ) 82,094 SF. 1.25 102,617.50
PAVEMENT (STREET) .
(21/13 ) 84,620 SF 1.50 126,930.00
HANDICAP RAMP 9 EA 500.00 4,500.00
SUB-TOTAL $382,185.10
STREET SIGNS
R-1 & STREET NAME SIGNS 2 EA 250.00 $ 500.00
NO PARKING SIGNS -0- -0- -0-
PRIVATE STREET SIGNS 2 EA 200.00 400.00
COMPACT CAR PAINTED SYMBOL 55 EA 25.00 1,375.00
VISTOR PARKING SIGN 5 EA 100.00 500.00
VISTOR YELLOW CURB 214 EA 5.00 1,070.00
HANDICAP SIGN & SYMBOL 8 EA 110.00 880.00
PARKING LOT STRIPING 510 EA 5.00 2,550.00
SUB-TOTAL $ 7,275.00
NO. 86525
4/9/87
PAGE 2 of 3
CITY BOND ESTIMATE
VILLAGE II - COTTONWOOD
WILLOW CREEK .
ITEM QUANTITY UNIT PRICE TOTAL
STORM DRAIN
10": P.V.C. 266 LF 18.00 $ 4,788.00
12" R.C.P. 405 LF 21.00 8,505.00
15" R.C.P. 346 LF „ 23.00 7,958.00
18" R.C.P. 259 LF 25.00 6,475.00
STANDARD DROP INLET
(SJ-405) 12 EA 1200.00 14,400.00
STANDARD FIELD INLET WITH
FRAME & GRATE 3 EA 1600.00 4,800.00
STANDARD MANHOLE TYPE "B" 1 EA 1500.00 1,500.00
SUB-TOTAL $48,426.00
GRAND TOTAL $437,886.10
BRIAN-KANGAS-FOULK & ASSOCIATES MAKES NO REPRESENTATION
CONCERNING THE ESTIMATED QUANTITIES AND COST FIGURES .
MADE IN CONNECTION WITH MAPS, PLANS, SPECIFICATIONS, OR
DRAWINGS, OTHER THAN THAT ALL SUCH FIGURES ARE ESTIMATES
ONLY AND THE ENGINEER/SURVEYOR SHALL NOT BE RESPONSIBLE
FOR FLUCTUATIONS IN COST FACTORS.
.CITY B0ND ESTIMATE • '.. 6/3/87
Page 3 of 3
VILLAGE II - CO7TONMM R&N
WILLOW CREEK
CFFSITFS
•
ITEM QUANTITY . UNIT PRICE TOTAL
Traffic Signal 1 IS $82,000.00 $82,000
Soundwall 6001 L $56.00 $33,600
Columns 11 IF $1,000.00 $11,000
Rail Fence 520 IF $20.00 $10,400
Dougherty 2,040 SQ.FT. $2.00 $4,080
Amador.Valley Blvd. 5,760 SQ.FT. $2.00 $11,520
Right Turn Lane
(Dougherty and Dublin Blvd.)
Demolition 1 IS $1,800.00 $1,800
Curb and Gutter 330 IF $8.00 $2,640
Sidewalk 1,980 SF $2.00 $3,960
Pavement (4",8",15") 2,250 SF $2.78 $6,255
Pavement Overlay . 4,500 SF $0.40 $1,800
Handicap Ramp 2 EA $500.00 $1,000
Electrical (2 Poles @ 2,500
(Vault @ 1,500
(Signals 10,000 1 LS $17,500.00 $17,500
Miscellaneous (raise iron drains) 1 IS $500.00 $500
Landscaping (Dougherty and AVB) 11,220 IF $2.00. $22,440
TOTAL OFFSITE $210,495.00
TOTAL ONSITE $437,886.00
TOTAL BOND $648,381.00
- Bond No. : 30 32 36
JC \A r_) J PERFORMANCE BOND
WHEREAS, the City Council of the City of Dublin, State of
California, and RAFANEL'L'I AND NAHAS (hereinafter designated as
"Principal"-) have entered into a contract under which Principal
is to install and complete certain designated public
improvements, identified as Amendment No. 1 to project Tract No.
5511, City of Dublin, State of California, which contract is
hereunto annexed and made a part hereof; and
WHEREAS, said principal is required under the terms of
said contract to furnish a bond for the faithful performance of
said Contract.
NOW, THEREFORE, we, the Principal, and INSURANCE COMPANY
OF THE WEST a corporation duly authorized to do business in the
State of California, as surety are held and firmly bound unto the
City of Dublin hereinafter called ( "City"-) , in the penal sum of
Six Hundred Forty Eight Thousand Three Hundred Eighty One and
No/100 Dollars ($.6.48, 381. 00-) lawful money of the United States,
for the payment of which sum well and truly to be made, we bind
ourselves, our heirs, successors, executors and administrators,
jointly and severally, firmly by these presents.
The condition of this obligation is such that if the above
bonded principal, his or its heirs, executors, administrators,
successors or assigns, shall in all things stand to and abide by,
and well and truly keep and perform the covenants, conditions and
provisions in the said contract and any alteration thereof made
as therein provided, on his or their part, to be kept and
performed at the time and in the manner therein specified, and in
all respects according to their true intent and meaning, and
shall indmenify and save harmless County, its officers, agents
and employees, as therein stipulated, then this obligation shall
become null and void; otherwise it shall be and remain in full
force and effect.
As a part of the obligation secured hereby and in addition
to the face amount specified therefor, there shall be included
costs and reasonable expenses and fees, including reasonable
attorney' s fees , incurred by City in successfully enforcing such
obligation, all to be taxed as costs and included in any judgment
rendered.
The surety hereby stipulates and agrees that no change,
extension of time, alteration or addition to the terms of the
contract or to the work to be performed thereunder or the
specifications accompanying the same shall in anyway affect its
obligations on this bond, and said surety does hereby waive
notice of any such change, extension of time, alteration or
addition to the terms of the contract or to the work or to the
specifications .
IN WITNESS WHEREOF`, this instrument is executed in four
counterparts, each one of which shall be deemed an original, by
the principal and surety above named, this 17th day of June,
1987.
(Principal-)
RAE`ANELLI AND NAHAS
BY:
Partner
(Surety-)
INSURANCE COMPANY OF THE-'WEST -
gy ` J
Attorney-in-E`act ,
�. i
.Bond 30 32 36
JUN
mv
1 IC WORKS PAYMENT BOND .
Labor & .Materials
WHEREAS, the -City 'Council of, the City .of Dublin- ;?',.State of
California, and RAFANELLI ..-AND ,. NAHAS :`. (hereinafter designated as
"Principal" ) have entered into a cont ract ' :under - °which Principal
is to install and complete . certain designated public
improvements, identified as `Amendment No. l to project Tract No.
5511, - City of Dublin, State of -California, which - contract : is
hereunto annexed and made a part hereof; and
WHEREAS, under the terms of `said contract, principal is
required before entering upon the performance - of ..:.the work, to
file a good and sufficient payment ;bond:with the ::City of Dublin
to secure ..,the claims .. to - which - reference is made An in Title 15
(Commencing with Section 3082) of Part .4 of Division .. 3 ':of : the
Civil Code of the ' State of California.
NOW THEREFORE, we the 'Principal, ' and INSURANCE COMPANY OF
THE WEST, a corporation duly . authorized to do business in the
State of California, as surety, - are- held and firmly bound ' unto
the City of Dublin and unto all . contractors; subcontractors,
laborers, materialmen and other persons employed in the
performance of the aforesaid contract and referred to in the
aforesaid Civil Code in the sum of Three Hundred Twenty Four
Thousand One Hundred Ninety One and no/100 Dollars
($324 ,191.00) for materials furnished or labor thereon of any
kind, . or for amounts due under the Unemployment Insurance Act
with respect to such work or labor, .and unto the Franchise Tax
Board of the State of California, that * said surety will pay the
same in an amount not exceeding the amount hereinabove set forth,
and also in case suit is brought upon this bond, will pay, in
addition to the face amount thereof, costs and reasonable
expenses and fees, including reasonable attorney's fees, incurred
by said City of Dublin in successfully enforcing such obligation,
to be awarded and fixed by the court, and to be taxed as costs
and to be included in the judgment therein rendered.
It is hereby expressly stipulated and agreed that this
bond shall inure to the benefit of any and all persons, companies
and corporations entitled to file claims under Title 15
( commencing with Section 3082) of part 4 of Division 3 of the
Civil Code so as to give a right of action to them or their
assigns in any suit brought upon this bond.
Should the condition of this bond be fully performed, then
this obligation shall become null and void, otherwise it shall be
and remain in full force and effect.
i .r t ^r.yUt it 1r' u t �E. ! ,r h r_s ;n. s F. �r"x 3 y.t'yVY 3P 7.( ti,}'liG3 fly, C•r ..ra'r3+- CJ' tfi A' 4:
.,'�.. p 1;'4... /.r„i .14 ( i SIF J t t r rrt i->"` ;. �"n /.,/l '�'• .A u: Yjit:� r �A,QrrF.J .. t,,t` rv' `
Y'.,.19�
.;p9 ,t. r'! ..r r;v;�s;i., �' �t'{I}. .Hier t..t•i q t' :r;�4 w r.,.. .1 l�(N.jz..`ti'} t�$,fi? x�'it;fr��f� �:rtiY{-r:t�iyrsgf�t �1.:�` "l j v'��?}'t'il,.Y ::,C,T+. .>
- 1 j ,•.4 J �., IFJ r'r'�' !�t 1 k�..t rz...r'r .-'w tir r..d fy i r' '��1.;: �Y }. rsl, y�'',• r r'r. ..r �I llr�s.'Y-✓ 7>r 1'* ,r.ri ry-
,t jlr��r.�.. ,r �• .t
y 1t :.( ' V '' y'f f' ,'}I x t�. :{ i?'kw t .:,!i � c tj u�M X• yl �N.n f1Y':.�s�'J".�:�:^'.l'1A�l..,y {i?�,-;�' r�p�'r7�a/gr.^r.� �t � pf ��,5'�> .r.. ...
r jf vi41 5.K! >.g. �Jf e „r' t r�g t y✓t t vft C sd' y r t 'tJrJ'F '4 t,h"1 �f'fii.�w�p?. � y{ �l• ( �<7.:r� ir$ a /t^.•�t r K 2�
'� � fr tl�,/ F t�s,'7..i�p+r 7 /y: tt a.'at'�. 1 r v .�:r' ry -.Cr '4�7 jn�'r'."••� rr' 'Yfa /[3 tlfrJ7 F7 s G�a( i�v h' 8,;.;...tti f
/ Y x -"�-ry 7 > f y f'f� :.f l t �,- 'r�' r �;'• j .f,'43 t if'.l 'dl �,71,f rI'..� J'd' it }.,fix{r / uy! 1�,d J t t, ICJ S�.^.,��I�iy
..... .,i;.•.'rr. 19i r�,lJ rnS). +u n ^v,., v :f.+ i !C r- / pf3. �A' "A '„rN rrf 7:! �,rh� �`}i1K�f'^ .,t.� l(�,�Vt'
> y r .'.+�, 1 ;v.+,lf < >.r r .Y't..r 'r 'ub'e iY✓' ,{•hxa 1 r -..� v �" �t+�• � rr, l r�•r{)�.,r�r. r3"r3 "� r-•"Z .
.-: ,... jl.t/i.t:y.-,..:'t J •'Yfi �..£,Tr I t 1 a �1L rt� M .,•T Yt 7"�F�l'A�:.��.Y�.'YL. �y,?:•�X d �{'••� 1•��� 7 4
t r 1• +x rW i,e"' r v zc ir. t aC' ;� +, ,a bx a ct ��x r5 � rs� t � Sa,3x
:�'. .,rr, Y ( r1t 1� )).t v�,, i �r 3 i rRr ��(e rr,nr '.{.. nrx jar '•s Y:�+.J'r�"}�Cj�:#) �/r3Y��1s fir=�.�w Cr i�'l,,.Nr�� r �if.�t�'u {a' vs °
� 11 "j ?41 ; fr t i� t" f r 'a..• r }w YTNy{ 5�d oa'f�'(l t ( t*'m � r 1. n3 F fr ,t f{ �' � .
� t t 'j-t
Ri,.„s"Jyrfr i••1 rj� S ltb.- �Y,t i.]" v J
fi.t47
' The . surety hereby stipulates and agreesfthat'no change, :;
extension'. -time,= alteration or :addition 'ao tthe :'terms Hof `said
:contract or . the- specifications '.accompanying ,,the ,.same -shall 'in ::any �;
manner -affect :its ,obligations on ',this :ibond,•''and 4�°it ':-0does hereby
..waive notice 'of any such . change,"-_;:extension; r::alteration -=or
addition x s
-.IN" .WITNESS r:.WHEREOF .. .this .instrument..`is executed in _four
counterparts,-eac h one of'which "shall be `deemed: an 'original `:'Nand .
: surety above `named;"this - 17th day of June1987 `�
(Principal) J
RAFANELLI 'AND 'NAHAS
Y
PARTNER
l
tr rl Jrt
(SURETY)
INSURANCE COMPANY OF:TEE• WEST
BY
ATTORNEY-IN-FACT,, L'-�;, ;,'•' t:y cj�
t 11JM1 a111• N11✓. M l aYI v . YR K U 11, : (AMI RI.rRr
t. I' 1 •/I•W'\'. V w a •t'w'K• K.K 11.N W.w 1471 Y r'II'1l•f 1i ••i •.. r ,�„1.7 ^
1 .11•w.r1•. r. ., . w•u.w• NI K � .:T RA C•T
.n' - •ra Ir
17L is W.•1 r13,11•r'1
■r•r•r•• r.r � • rww• r<r' •t,.A ar,W rLw ■n•n•w•t 1 D
1 }�y. • ■r'r'Y'r r.11. • r'w'W K.r 7•.N w K )1.11 ■Y'r'Y'• VI�� hY � •• >F
.1,r• W r.0 11.51 r•t .11 N 1t•. =1� CITY 'OF DUBLIN
I • •N'w'M'r 1r K '1 n V,r S A
Fr� sF ' 1'•w w w. 1K W t in u r °:» - ',64:;; ii:; ;;�,-M, sfrE,'. ALAMEDA COUNTY.�, CALIFORNIA♦
y. t • ■W161r•t w Y
*�+' s _at s t. '+ .:• ■
in'
t r !: ;,•Y••.:3�•s,r+ i
w Y 1.17 r '`- Iw K i•'''` BEING.A'.SUBDIVISION OF•"':PARCELtMAP'
r,.w
t r3 >t t# t 13 •r r r It It r:, v 4575 AS SHOWN IN MAP BOOK:155 AT'PAGE;
Bit s y. Y ■rrrr- rw
y W t [♦� It .u r r I r r a ALAMEDA`COUNTY RECORDS;;• CALIFORNIA ;
t` t; +�- t s W ■r o r. we•1 b1 sv.e V//c/ ITr.MA/ t i ...• ,, .. ti:r•6L '
} 11 •r'r'rY W 11 - er- - ` /r 1'� t _. �• 7 �•`.. ✓M t.l�'_
w ■r r nv r w s It t./•II SCALE y l IN .200FT :DATE
w ■rrur rr a •. ,r a
TETRAD ENGINEERING "'INC
Gw•daft MARTINEZ CALIFORNIA•, 1r 't I
ROAD
a •� IIERfY •'Oal•Vt a'
Y- n. 7 ,.�,I nit�'r DOl!( - 11._•+ ^�.'UIy), 9r/! -`- .. + !••I//I Y 4r5,�• ,
s = t. •R + tor •C 1 .a
��~-'l♦IlO.n'Yr1IY /ylN H�MIN• .. . i Nlr/' f.y.. 1 .Yti .k-
' Y+ 1
or
z: AiIA0 it
J� I W',1 J •f Grp
[Ol 140 1 t.1 r:. �. •j `� '1 np 1 'Lot 148
Lor lfO t•
cl
� .- �� � plfnl.t".�U�- ♦♦ I �L lI ♦ 1�Y
-- x .. . .�' - ♦ ? � �� `'' •; � its
{ ; N: tot Y' r CgFt.A, RC•Er , 'y.l'' •, f .) Sr tLi+ rim'
t , t - / \•\ t o P;Z
OY / tOl•l.t r + ^'� \ .4p• .,�s F���' T 1c.S
for
bIt
, ,P Lo •c• -;fit.
{- - f Ca° •�. ! IRA: 17 9 p» y � l `•Sf
k Lot
RO IZ Ail 4t
era `I — --'t- t. •�••vtc• com?r rt000 CON [ 1 s , +
i - --- - WJICR CONitRi.TrON 0/STRICT + t `.v
a1RCtL'c'stRrts,a a ort»f ' ' - , '•- - - ,`-
Lot �,,,♦ 7 ' ..
t
Ir1 r ��-- } r, -.•� 1 1 • • ;d KK.at' "`,� ,•.1.''t ; _9
two rr.-o-ca r `
Lor 1f.7 mAcr.»t--l.r a 47 •'9 r,
f • rDm I.•1.>p.rtrt 1 IY U•t7• !
r 1 . i's
T
1 _ .• - ' •'% /r•o t.1 t■I■rl ryIt 1 IK Ka Will Rti rl'':i c-11 q.h1a ass,>L c3i:r. -l:
¢ l/Sq Or 8E1RINGt 5 ' • A
r two Iqf :.y,. • If.,i a Ir t�a..•ru11 t•tt
a - •Ha y•,II•T•IIr f�Jb "IK LiK IfIW■IK/aro UKtt YpHf,O PNVI �Wtat•LIK M r.• r»
- .. M1K IK K..r•n L,K d tav■11 tow - �..Ulrxrl tr/n.r■t/11/ �atii uwt�>. y r c ri� Fkr + s�y,:•<�•r.
_ • ..