HomeMy WebLinkAboutItem 4.06 Civic Ctr Crtyard Accpt Improv (2) GITY OF DUBLIN
AGENDA STATEMENT
City Council Meeting Date: February 11, 1991
SUBJECT:
Acceptance of Work - Contract No. 89-8 Civic Center
Courtyard Fountain
Report by Public Works Director Lee Thompson
EXHIBITS ATTACHED:
None.
RECOMMENDATION:
1)
x\~ 2)
3)
Accept improvements under Contract 89-8
Authorize retention payment, less liquidated
damages, in the amount of $7,877 to Golden Bay
Construction.
Authorize budget transfer in the amount of $7,877
to this project from unallocated reserves.
FINANCIAL STATEMENT:
Construction
Construction Contingency
Architect's Const. Service
Inspection
Less liquidated damages
Budget Actual
$ 113,770.00 $ 113,770.00
10,000.00 0.00
3,000.00 1,670.50
4~500.00 566.93
$ 131,270.00 $ 127,384.43
(-3,500.00)
$ 123,884.43
Funding for this project was approved by the City Council as follows
$125,000 from Dublin Information, Inc., 1988-89 interest earnings
6,300 from the Civic Center Capital Improvement Project
$131,300
Although this project is $7,385.57 under budget, all the funds were budgeted
in Fiscal Year 1989-90. No funds were budgeted for FY1990-91; therefore a
budget transfer from unallocated reserves is necessary to pay the remaining
$7,877 to the contractor.
DESCRIPTION: On October 30, 1989, the City Council awarded
Contract 89-8 Civic Center Courtyard Fountain to Golden Bay Construction.
This project, which was designed by David Gates and Associates, constructed
a water element in the courtyard of the Civic Center supports the globe
sculpture that was recently installed by the Dublin Fine Arts Foundation.
Most of the project was completed ahead of schedule; however, the slate
lining that was specified for the fountain delayed the project for some time
causing liquidated damages in the amount of $3,500.
The City Engineer has determined that the work was completed in accordance
with the approved plans and specifications. Staff recommends that the City
Council accept the improvements and authorize retention payment, less
liquidated damages, to Golden Bay Construction in the amount of $7,877.